AGR-4802.H - GEOLOGIC ASSOCIATES INC - RESERVOIR 2A GEOTECHNICAL MONITORING SERVICESl.F'l "O tl
V\
PROFESSIONAL SERVICES AGREEMENT
Reservoir 2A Geotechnical Monitoring Services]
THIS PROFESSIONAL SERVICES A REEMENT (the "Agreement") is made at
Orange, California, on this ?jo+ day of f oVei11 e;r , 2020 (the "Effective Date") by and
between the CITY OF ORANGE, a municipal corporation ("City"), and GEOLOGIC
ASSOCIATES, INC., a California corporation ("Contractor"), who agree as follows:
1. Services. Subject to the terms and conditions set forth in this Agreement,
Contractor shall provide to the reasonable satisfaction of City the services set forth in Exhibit"A,"
which is attached hereto and incorporated herein by reference. As a material inducement to City
to enter into this Agreement, Contractor represents and warrants that it has thoroughly investigated
and considered the scope of services and fully understands the difficulties and restrictions in
performing the work. The services which are the subject of this Agreement are not in the usual
course of City's business and City relies on Contractor's representation that it is independently
engaged in the business of providing such services and is experienced in performing the work.
Contractor shall perform all services in a manner reasonably satisfactory to City and in a manner
in conformance with the standards of quality normally observed by an entity providing such
services to a municipal agency. All services provided shall conform to all federal, state and local
laws, rules and regulations and to the best professional standards and practices. The terms and
conditions set forth in this Agreement shall control over any terms and conditions in Exhibit "A"
to the contrary.
Tuan Cao, Senior Civil Engineer("City's Project Manager"), shall be the person to whom
Contractor will report for the performance of services hereunder. It is understood that Contractor's
performance hereunder shall be under the supervision of City's Project Manager (or his/her
designee), that Contractor shall coordinate its services hereunder with City's Project Manager to
the extent required by City's Project Manager, and that all performances required hereunder by
Contractor shall be performed to the satisfaction of City's Project Manager and the City Manager.
2. Compensation and Fees.
a. Contractor's total compensation for all services performed under this
Agreement, shall not exceed EIGHT THOUSAND NINE HLJNDRED FIVE DOLLARS and
00/100 ($8,905.00)without the prior written authorization of City.
b. The above compensation shall include all costs, including, but not limited
to, all clerical, administrative, overhead, insurance, reproduction, telephone, travel, auto rental,
subsistence and all related expenses.
3. Pavment.
a. As scheduled services are completed, Contractor shall submit to City an
invoice for the services completed, authorized expenses and authorized extra work actually
performed or incurred.
b. All such invoices shall state the basis for the amount invoiced, including
services completed,the number of hours spent and any extra work performed.
c. City will pay Contractor the amount invoiced within thirty (30) days after
the approval of the invoice.
d. Payment shall constitute payment in full for all services, authorized costs
and authorized extra work covered by that invoice.
4. Chan e Orders. No payment for extra services caused by a change in the scope
or complexity of work, or for any other reason, shall be made unless and until such extra services
and a price therefor have been previously authorized in writing and approved by City as an-
amendment to this Agreement. CiTy's Project Manager is authorized to approve a reduction in the
services to be performed and compensation therefor. All amendments shall set forth the changes
of work, extension of time,and/or adjustment of the compensation to be paid by City to Contractor
and shall be signed by the City's Project Manager, City Manager or City Council, as applicable.
5. Licenses. Contractor represents that it and any subcontractors it may engage,
possess any and all licenses which are required under state or federal law to perform the work
contemplated by this Agreement and that Contractor and its subcontractors shall maintain all
appropriate licenses, including a City of Orange business license, at its cost, during the
performance of this Agreement.
6. Independent Contractor. At all times during the term of this Agreement,
Contractor shall be an independent contractor and not an employee of City. City shall have the
right to control Contractor only insofar as the result of Contractor's services rendered pursuant to
this Agreement. City shall not have the right to control the means by which Contractor
accomplishes services rendered pursuant to this Agreement. Contractor shall, at its sole cost and
expense, furnish all facilities, materials and equipment which may be required for furnishing
services pursuant to this Agreement. Contractor shall be solely responsible for, and shall
indemnify, defend and save City harmless from all matters relating to the payment of its
subcontractors, agents and employees, including compliance with social security withholding and
all other wages, salaries, benefits, taxes, exactions, and regulations of any nature whatsoever.
Contractor acknowledges that it and any subcontractors, agents or employees employed by
Contractor shall not,under any circumstances,be considered employees of City,and that they shall
not be entitled to any ofthe benefits or rights afforded employees of City,including,but not limited
to, sick leave, vacation leave, holiday pay, Public Employees Retirement System benefits, or
health, life, dental, long-term disability or workers' compensation insurance benefits.
7. Contractor Not A ent. Except as City may specify in writing, Contractor shall
have no authority, express or implied, to act on behalf of City in any capacity whatsoever as an
agent. Contractor shall have no authority, express or implied, to bind City to any obligation
whatsoever.
2
8. Desi nated Persons. Only those qualified persons authorized by City's Project
Manager, or as designated in E ibit"A," shall perform work provided for under this Agreement.
It is understood by the parties that clerical and other nonprofessional work may be performed by
persons other than those designated.
9. Assignment or Subcontractin. No assignment or subcontracting by Contractor
of any part of this Agreement or of funds to be received under this Agreement shall be of any force
or effect unless the assignment has the prior written approval of City. City may terminate this
Agreement rather than accept any proposed assignment or subcontracting. Such assignment or
subcontracting may be approved by the City Manager or his/her designee.
10. Time of Comnletion. Except as otherwise specified in Exhibit "A," Contractor
shall commence the work provided for in this Agreement within two(2)days of receipt of a Notice
to Proceed and diligently prosecute completion of the work in accordance with the time period set
forth in Exhibit "A" hereto or as otherwise agreed to by and between the representatives of the
parties.
11. Time Is of the Essence. Time is of the essence in this Agreement. Contractor shall
do all things necessary and incidental to the prosecution of Contractor's work.
12. Reserved.
13. Delays and Extensions of Time. Contractor's sole remedy for delays outside its
control, other than those delays caused by City, shall be an extension of time. No matter what the
cause of the delay,Contractor must document any delay and request an extension of time in writing
at the time of the delay to the satisfaction of City. Any extensions granted shall be limited to the
length of the delay outside Contractor's control. If Contractor believes that delays caused by City
will cause it to incur additional costs, it must specify, in writing, why the delay has caused
additional costs to be incurred and the exact amount of such cost at the time the delay occurs. No
additional costs can be paid that exceed the not to exceed amount stated in Section 2.a, above,
absent a written amendment to this Agreement.
14. Products of Contractor. The documents, studies, evaluations, assessments,
reports,plans, citations, materials, manuals,technical data, logs, files, designs and other products
produced or provided by Contractor for this Agreement shall become the property of City upon
receipt. Contractor shall deliver all such products to City prior to payment for same. City may
use,reuse or otherwise utilize such products without restriction.
15. Equal Emnlovment Onnortunitv. During the performance of this Agreement,
Contractor agrees as follows:
a. Contractor shall not discriminate against any employee or applicant for
employment because of race, color, religion, sex, national origin, mental or physical disability, or
any other basis prohibited by applicable law. Contractor shall ensure that applicants are employed,
and that employees are treated during employment, without regard to their race, color, religion,
sex, national origin,mental or physical disability, or any other basis prohibited by applicable law.
3
Such actions shall include,but not be limited to the following: employment,upgrading, demotion
or transfer,recruitment or recruitment advertising,layoff or termination,rates of pay or other forms
of compensation and selection for training, including apprenticeship. Contractor agrees to post in
conspicuous places, available to employees and applicants for employment, a notice setting forth
provisions of this non-discrimination clause.
b. Contractor shall, in all solicitations and advertisements for employees
placed by, or on behalf of Contractor, state that all qualified applicants will receive consideration
for employment without regard to race, color, religion, sex, national origin, mental or physical
disability, or any other basis prohibited by applicable law.
c. Contractor shall cause the foregoing paragraphs (a)and(b)to be inserted in
all subcontracts for any work covered by this Agreement, provided that the foregoing provisions
shall not apply to subcontracts for standard commercial supplies or raw materials.
16. Conflicts of Interest. Contractor agrees that it shall not make, participate in the
making, or in any way attempt to use its position as a consultant to influence any decision of City
in which Contractor knows or has reason to know that Contractor, its officers, partners, or
employees have a financial interest as defined in Section 87103 of the Government Code.
Contractor further agrees that it shall not be eligible to work as the design/build firm for the project
that is the subject of this Agreement.
17. Indemnitv.
a. To the fu(lest extent permitted by law, Contractor agrees to indemnify,
defend and hold City, its City Council and each member thereof, and the officers, officials, agents
and employees of City(collectively the "Indemnitees") entirely harmless from all liability arising
out of:
1) Any and all claims under workers' compensation acts and other
employee benefit acts with respect to Contractor's employees or Contractor's subcontractor's
employees arising out of Contractor's work under this Agreement, including any and all claims
under any law pertaining to Contractor or its employees' status as an independent contractor and
any and all claims under Labor Code section 1720 related to the payment of prevailing wages for
public works projects; and
2) Any claim, loss, injury to or death of persons or damage to property
caused by any act, neglect, default, or omission other than a professional act or omission of
Contractor, or person, firm or corporation employed by Contractor, either directly or by
independent contract, including all damages due to loss or theft sustained by any person, firm or
corporation including the Indemnitees, or any of them, arising out of, or in any way connected
with the work or services which are the subject of this Agreement, including injury or damage
either on or off City's property; but not for any loss, injury, death or damage caused by the active
negligence or willful misconduct of City. Contractor, at its own expense, cost and risk, shall
indemnify any and all claims, actions, suits or other proceedings that may be brought or instituted
against the Indemnitees on any such claim or liability covered by this subparagraph, and shall pay
4
or satisfy any judgment that may be rendered against the Indemnitees, or any of them, in any
action, suit or other proceedings as a result of coverage under this subparagraph.
b. To the fullest extent permitted by law, Contractor agrees to indemnify and
hold Indemnitees entirely harmless from all liability arising out of any claim, loss, injury to or
death of persons or damage to property caused by its negligent professional act or omission in the
performance of professional services pursuant to this Agreement.
c. Except for the Indemnitees, the indemnifications provided in this
Agreement shall not be construed to extend any third party indemnification rights of any kind to
any person or entity which is not a signatory to this Agreement.
d. The indemnities set forth in this section shall survive any closing,
rescission,or termination of this Agreement, and shall continue to be binding and in full force and
effect in perpetuity with respect to Contractor and its successors.
18. Insurance.
a. Contractor shall carry workers' compensation insurance as required by law
for the protection of its employees during the progress of the work. Contractor understands that it
is an independent contractor and not entitled to any workers' compensation benefits under any
City program.
b. Contractor shall maintain during the life of this Agreement the following
minimum amount of comprehensive general liability insurance or commercial general liability
insurance: the greater of (1) One Million Dollars ($1,000,000) per occurrence; or (2) all the
insurance coverage and/or limits carried by or available to Contractor. Said insurance shall cover
bodily injury, death and property damage and be written on an occurrence basis.
c. Contractor shall maintain during the life of this Agreement, the following
minimum amount of automotive liability insurance: the greater of(1) a combined single limit of
One Million Dollars ($1,000,000); or (2) all the insurance coverage and/or limits carried by or
available to Contractor. Said insurance shall cover bodily injury, death and property damage for
all owned, non-owned and hired vehicles and be written on an occurrence basis.
d. Any insurance proceeds in excess of or broader than the minimum required
coverage and/or minimum required limits which are applicable to a given loss shall be available
to City. No representation is made that the minimum insurance requirements of this Agreement
are sufficient to cover the obligations of Contractor under this Agreement.
e. Each policy of general liability and automotive liability shall provide that
City, its officers, officials, agents, and employees are declared to be additional insureds under the
terms of the policy, but only with respect to the work performed by Contractor under this
Agreement. A policy endorsement to that effect shall be provided to City along with the certificate
of insurance. In lieu of an endorsement, City will accept a copy of the policy(ies)which evidences
5
that City is an additional insured as a contracting party. The minimum coverage required by
Subsection 18.b and c, above, shall apply to City as an additional insured.
f.Contractor shall maintain during the life of this Agreement professional
liability insurance covering errors and omissions arising out of the performance of this Agreement
with a minimum limit of One Million Dollars ($1,000,000)per claim. Contractor agrees to keep
such policy in force and effect for at least five (5) years from the date of completion of this
Agreement.
g. The irisurance policies maintained by Contractor shall be primary insurance
and no insurance held or owned by City shall be called upon to cover any loss under the policy.
Contractor will determine its own needs in procurement of insurance to cover liabilities other than
as stated above.
h. Before Contractor performs any work or prepares or delivers any materials,
Contractor shall furnish certificates of insurance and endorsements, as required by City,
evidencing the aforementioned minimum insurance coverages on forms acceptable to City,which
shall provide that the insurance in force will not be canceled or allowed to lapse without at least
ten (10) days' prior written notice to City.
i.Except for professional liability insurance coverage that may be required by
this Agreement, all insurance maintained by Contractor shall be issued by companies admitted to
conduct the pertinent line of insurance business in California and having a rating of Grade A or
better and Class VII or better by the latest edition of Best Key Rating Guide. In the case of
professional liability insurance coverage, such coverage shall be issued by companies either
licensed or admitted to conduct business in California so long as such insurer possesses the
aforementioned Best rating.
j Contractor shall immediately notify City if any required insurance lapses or
is otherwise modified and cease performance of this Agreement unless otherwise directed by City.
In such a case, City may procure insurance or self-insure the risk and charge Contractor for such
costs and any and all damages resulting therefrom, by way of set-off from any sums owed
Contractor.
k. Contractor agrees that in the event of loss due to any of the perils for which
it has agreed to provide insurance, Contractor shall look solely to its insurance for recovery.
Contractor hereby grants to City,on behalf of any insurer providing insurance to either Contractor
or City with respect to the services of Contractor herein,a waiver of any right to subrogation which
any such insurer may acquire against City by virtue of the payment of any loss under such
insurance.
I.Contractor shall include all subcontractors, if any, as insureds under its
policies or shall furnish separate certificates and endorsements for each subcontractor to City for
review and approval. All coverages for subcontractors shall be subject to all of the requirements
stated herein.
6
19. Termination. City may for any reason terminate this Agreement by giving
Contractor not less than five (5) days' written notice of intent to terminate. Upon receipt of such
notice, Contractor shall immediately cease work, unless the notice from City provides otherwise.
Upon the termination of this Agreement, City shall pay Contractor for services satisfactorily
provided and all allowable reimbursements incurred to the date of termination in compliance with
this Agreement, unless termination by City shall be for cause, in which event City may withhold
any disputed compensation. City shall not be liable for any claim of lost profits.
20. Maintenance and Insnection of Records. In accordance with generally accepted
accounting principles, Contractor and its subcontractors shall maintain reasonably full and
complete books, documents, papers, accounting records, and other information (collectively, the
records")pertaining to the costs of and completion of services performed under this Agreement.
City and its authorized representatives shall have access to and the right to audit and reproduce
any of Contractor's records regarding the services provided under this Agreement. Contractor shall
maintain all such records for a period of at least three (3)years after termination or completion of
this Agreement. Contractor agrees to make available all such records for inspection or audit at its
offices during normal business hours and upon three(3)days' notice from City,and copies thereof
shall be furnished if requested.
21. Compliance with all Laws/Immi ration Laws.
a. Contractor shall be knowledgeable of and comply with all local, state and
federal laws which may apply to the performance of this Agreement.
b. If the work provided for in this Agreement constitutes a"public works," as
that term is defined in Section 1720 of the California Labor Code,for which prevailing wages must
be paid, to the extent Contractor's employees will perform any work that falls within any of the
classifications for which the Department of Labor Relations of the State of California promulgates
prevailing wage determinations, Contractor hereby agrees that it, and any subcontractor under it,
shall pay not less than the specified prevailing rates of wages to all such workers. The general
prevailing wage determinations for crafts can be located on the website of the Department of
Industrial Relations (www.dir.ca.ov/DLSR). Additionally,to perform work under this Contract,
Contractor must meet all State registration requirements and criteria, including project compliance
monitoring.
c. Contractor represents and warrants that Contractor:
1) Has complied and shall at all times during the term of this
Agreement comply, in all respects, with all immigration laws, regulations, statutes, rules, codes,
and orders, including, without limitation, the Immigration Reform and Control Act of 1986
IRCA); and
2) Has not and will not knowingly employ any individual to perform
services under this Agreement who is ineligible to work in the United States or under the terms of
this Agreement; and
7
3) Has properly maintained, and shall at all times during the term of
this Agreement properly maintain, all related employment documentation records including,
without limitation, the completion and maintenance of the Form I-9 for each of Contractor's
employees; and
4) Has responded, and shall at all times during the term of this
Agreement respond, in a timely fashion to any government inspection requests relating to
immigration law compliance and/or Form I-9 compliance and/or worksite enforcement by the
Department of Homeland Security, the Department of Labor, or the Social Security
Administration.
d. Contractor shall require all subcontractors or subconsultants to make the
same representations and warranties as set forth in Subsection 21.c.
e. Contractor shall, upon request of City, provide a list of all employees
working under this Agreement and shall provide,to the reasonable satisfaction of City,verification
that all such employees are eligible to work in the United States. All costs associated with such
verification shall be borne by Contractor. Once such request has been made, Contractor may not
change employees working under this Agreement without written notice to City, accompanied by
the verification required herein for such employees.
f.Contractor shall require all subcontractors or sub-consultants to make the
same verification as set forth in Subsection 21.e.
g. If Contractor or subcontractor knowingly employs an employee providing
work under this Agreement who is not authorized to work in the United States, and/or fails to
follow federal laws to determine the status of such employee,that shall constitute a material breach
of this Agreement and may be cause for immediate termination of this Agreement by City.
h. Contractor agrees to indemnify and hold City, its officers, officials, agents
and employees harmless for, of and from any loss, including but not limited to fines,penalties and
corrective measures City may sustain by reason of Contractor's failure to comply with said laws,
rules and regulations in connection with the performance of this Agreement.
22. Governin Law and Venue. This Agreement shall be construed in accordance
with and governed by the laws of the State of California and Contractor agrees to submit to the
jurisdiction of California courts. Venue for any dispute arising under this Agreement shall be in
Orange County, California.
23. Inte ration. This Agreement constitutes the entire agreement of the parties. No
other agreement,oral or written,pertaining to the work to be perfortned under this Agreement shall
be of any force or effect unless it is in writing and signed by both parties. Any work performed
which is inconsistent with or in violation of the provisions of this Agreement shall not be
compensated.
8
24. Notice. Except as otherwise provided herein, all notices required under this
Agreement shall be in writing and delivered personally, by e-mail, or by first class U.S. mail,
postage prepaid, to each party at the address listed below. Either party may change the notice
address by notifying the other party in writing. Notices shall be deemed received upon receipt of
same or within three (3) days of deposit in the U.S. Mail,whichever is earlier. Notices sent by e-
mail shall be deemed received on the date of the e-mail transmission.
CONTRACTOR" CITY"
Geologic Associates, Inc. City of Orange
2777 East Guasti Road, Suite 1 300 E. Chapman Avenue
Ontario, CA 91761 Orange, CA 92866-1591
Attn.: John Hower, Sr. Vice President Attn.: Jose M. Diaz, Water Manager
Telephone: (909) 626-2282 Telephone: (714)288-2475
E-Mail: jmhower@geo-logic.com E-Mail: jdiaz@cityoforange.org
25. Counteraarts. This Agreement may be executed in one or more counterparts,each
of which shall be deemed an original, but all of which together shall constitute one and the same
instrument. Signatures transmitted via facsimile and electronic mail shall have the same effect as
original signatures.
Remainder of page intentionally left blank; signatures on next page]
9
IN WITNESS of this Agreement, the parties have entered into this Agreement as of the
year and day first above written.
CONTRACTOR" CITY"
GEOLOGIC ASSOCIATES, INC. CITY OF ORANGE, a municipal corporation
a California corporation
By: By:
Printed ame: Gary L. Lass i Otto, City Manager
Title: Chairman of the Board
By:
Print Name:John M. Hower
Title: Secretary APPROVED AS TO FORM:
l t, '
Mary E. Bi ing
Senior Ass stant City Atto ey
XNOTE:City requires the following signature(s) on behalf of the Contractor:
1)the Chairman of the Board,the President or a Vice-President,AND (2)the
Secretary, the.Chief Financial Officer, the Treasurer, an Assistant Secretary
or an Assistant Treasurer. If only one corporate officer exists or one corporate
officer holds more than one corporate office, please so indicate. OR
The corporate officer named in a corporate resolution as authorized to enter
into this Agreement. A copy of the corporate resolution, certified by the
Secretary close in time to the execution of the Agreement, must be provided to
City.
10
EXHIBIT "A"
SCOPE OF SERVICES
Beneath this sheet.]
Ge o-Loq:ic
ASSOC_IAT.ES/
Engineers,Geologists,and Hydrogeologists
October 29, 2020 :.
5020.214:PR.
Mr.Tuan Cao
City of Orange Water Department
189 South Water Street
Orange; CA. 92866
PROPOSAL.FOR 2020 GEOTECHNICAL MONITORING OF RESERVOIR 2A '
2444 VISTA POINT ROAD, LOT 192,TRACT 10439
ORANGE; CALIFORNIA
INTRODUCTION
As:requested, Geo-Logic Associates, Inc. (GLA) is pleased to present this proposal to the City of
Orange Water Department (VUater Department) . to continue annual geotechnical
instrumentation monitoring and site observation at tlie.2A Reservoir site. Scope of rivork includes
inclin.ometer reading;groundwater elevation recording;observation of distress such as.cracking
and/or bulging, logging of dedicated crack monitors (crack gauges)and review of optical survey
data, . Supporting work will 'include compilation and reduction of data, data review, and ,
presentation of data in a format su.itable.for engineering evaluations.
BACKGROUND
The 2A ReserVoir is a cylindrical steel_tank constructed in or around 1986. Approximate location
of tlie 2A Reservo,ir is.shown in.Figure`1. Street address is 2444 Vista Point Road. The.tank is . ,
approximately 140 feet in diameter and is approximately 20 feet tall.
Geotechnical instrumentation at the site has been monitored. by GLA since 2004. GLA
observations have been documentecl in a form suitable for engineering interpretation, including
as profiles of ongoing, incremerital movement; groundwater e_levation profiles, and vectors of
movement shown on annual topographic surveys.
Our repor.ts.indicate that, since 2004; the 2A Reservoir site is settling and is moving in IateraL
direction towards the surrounding residences.
SCOPE OF WORK . .
The proposed scope ofwork is limited to collection and processing of recor.ded and observational
data. . Professional interpretation of this information,.including an.assessment.of site stability,
and/or establishment of action levels is beyond the scope of our services.
Geo-Logic Associates 3150 Bristol Street;$uite 210,Costa Mesa,CA • 714-465-8240•www.Geo=Logic.com - •
Field Work
Record slope movement, if.any;in;five sfope inclinometers casings.
Observ.e groundwater elevation in eight piezometer casings.
Record position of four crack comparator gauges:
Record visible distress/movement features on a site. plan and ,r.ecord
magnitude of separations/offsets.
Obse ve and photo-document general site conditions.
Review Water Department.optical survey data,.compile in tabular and in .
chart form.
Reduce inclinometer data, compare with previous reading sets and plot in . -
tabular. and%or chart form. .
Reduce piezometer readings and update charts and tables.
Update distress/movement features on site plan.
Reportin
Summary of observed site conditions and discussion pertinent to significant
changes in ground .conditions and distress/movement features since
previous observation/measurement date.
Discussion of significant changes in groundwater levels since previou.s. .
readings, if applicable.
Discussion ofsignificant suivey monument changes since previous readings,
if applicable. _
Discussion of significant inclinometer casing changes since previous
readings, if applicable.
Recommendations for the need of continued monitoring and/or additional
geotechnical study, ifi applicable.
ASSUMPTIONS
1. Rights-of-access w.ill be obtained and provided for GLA by the Client.
2. There is no.allowance.#or traffic control/permits during reading of the piezometers or
inclinometers in the street.,
3: Allowance cost has.been made for one post-report meeting at the City of Orange Water
Department. Additional effort/meetings may be provided on a time-and=materials basis
in accordance with our 2020 Fee Schedule hourly rates as shown in Table 1.
4. GLA will not be responsible for. .repairs; maintenance, and abandonment of. the
boring/piezometers. If desired .at a .later date, GLA can arrange for the proper
abandonment of the piezometers at additional cost: - .
5. The Water Department will consult with a structural engineer to evaluate the cumulative
movement recorded in the soils will not damage or cause nexpected failure of the tank.
DATA NEEDS
We request that the Water Department provides the annual.on-site elevation survey data.to GLA:
We request this information in AutoCAD format with elevations turned on. GLA will review and
Proposal 5020.1214.PR 2A Reservoir Monitoring 2020 2
Octotier 29,2020 . . . ,
4- . . . - . . . - " . . .' , , - . . _ - " .
incorporation into our.report of findings.
SCHEDULE:.
GLA is r.eady to star.t working on.this pr.oject within two days from receipt of fully executed
contract from the City of Orange Water Department and a formal Notice to.Rroceed (NTP.).
GLA estimates that field work will be completed within three weeks of receipt of NTP.. Following
execution of the field work, and receipt of the annual on-site elevation survey, data; GLA will.
submit an internally peer-reviewed draft report to the Water Department_within 3 weeks. Please
let us_know if more aggressive schedule is required.
The.final report will be signed and sealed bya Professional Engineer (PE) registered in the State
of California. lt will be issued no later than.one week upon receipt of comments on the draft
report: . .
COST ESTIMATE
The total estimated cost to complete the 2020 observation is$8,905.00. A cost breakdown has
been provided in the attac.hed 7able 1 below.
GLA will conduct:the services, in a manner consistent with or exceeding a level of care and skill .
ordinarily exercised by members of the same profession performing similar tasks.
CLOSING
If you have any questions regarding the proposal, please do not hesitate to contact Greg Shagam
at (858) 248-9496:
We_appreciate the opportunity to be of service and to continue our relationship with the City of
Orange Water Department.
Sincerely;
Geo-Logic Associates,. Inc.
i
Jr:,.' /%lti.-r'*'
s
f
Jose h G. Franzone;GE Gre Sha am, PG, CEG .g g
Supervising Geotechnical Engineer Project Engineering Geologist lll
Attachments: .Figure 1—Vicinity Map
Table 1-Cost Estimate
Distribution; .(1)Addressee-El ctronic submittal
Proposal 5020.1214.PR 2A Reservoir Monitoring 2020 3
Octo6er 29;2020
TABLE 1-COST ESTIMATE
GEOTECHNICAL INSTRUMENTATIQN MONITORING,Z020
2A RESERVOIR . :
PROPOSAL N0.5020.1214:PR
Catesory uanti Unit Rate _ Amount Total
Field Exploration 2,660.00
Projecf Geologist III with vehicle 14 hour . 190.00 $2,660.00
Office Analvsis,Report Preparation,Office Visit 6,245.00 .
Project.Geologist III 16 hour 190.00 $3,040.00
Principal Engineer 8 houc . . 250:00 $2,000.00
Word_Processor 5 hour 85.00 425:00
Drafting%CAD 6 hour 130.00 780.00
Total 8,905.00
Proposal 5020.1214.PR 2A Reservoir Monitoring 2020 4
October 29,2020 •-
jr'i t c4- , r -
k
1 / M
r ..• i 5' r:. 3
1
r
x. , ; ' .i.
a 51
Y t; i-
I,
H' , •
i" YS.
lr ` ' r '(
1 .' M -
l' (-. `,
I11/ _
r;
G'
k i J:J _ `_...
7
y i L
t ,'t 1 •
x ,
i
x
r j b'
Y L I
S J„
s.
k-
I
t
7 lC+.,.L n`i,w R I j" .
M a .. 1
3
i
S f
I. ' P R OJECT SITE ~
Y:
f
o .
A
a
t
w {`\ t `:
i!
t '
r
f
5 .
i
t
4/ .
v'
y
t : 7. yl 1 f'
r
d!'' r y
i , ;
r -r'
o j , -.v coJ;...
M V
s `,.+C /.' `t.- _ ti. '"'1:4
REFERENCE: Google Earth, Imagery dated April 2018.
N
0 200 400 FEET
1 1 1
APPROXIMATE SCALE
I FIGURE 1
VICINITY MAP
GEOTECHNICAL REPORT
2020 MONITORING - RESERVOIR 2A
I CITY OF ORANGE, CALIFORNIA
Geo-Lo9ic
A S S O C 1 A T E S
Draft Date Project No.
JGF 10/2020 S020.1214