AGR-7069 - TRIAD CONSULTING & SYSTEM DESIGN GROUP LLC - SECURITY CONSULTING AND DESIGN SERVICES - INTRUSION ALARMSR-7ob
PROFESSIONAL SERVICES AGREEMENT
Security Consulting and Design Services—Intrusion Alarms]
THIS PROFESSIONAL SERVICES AG EMENT (the "Agreement") is made at
Orange, Califor'nia, on this 1C h day of Nm e eX 2020 (the "Effective Date") by and
between the CITY OF ORANGE, a municipal corporation ("City"), and TRIAD CONSITLTING
SYSTEM DESIGN GROUP,LLC, a California limited liability company("Contractor"),who
agree as follows:
1. Services. Subject to the terms and conditions set forth in this Agreement,
Contractor shall provide to the reasonable satisfaction of City the services set forth in E ibit"A,"
which is attached hereto and incorporated herein by reference. As a material inducement to City
to enter into this Agreement,Contractor represents and warrants that it has thoroughly investigated
and considered the scop.e of services and fully understands the difficulties and restrictions in
performing the work. The services which are the subject of this Agreement are not in the usual
course of City's business and City relies on Contractor's representation that it is independently
engaged in the business of providing such services and is experienced in performing the work.
Contractor shall perform all services in a manner reasonably satisfactory to City and in a manner
in conformance with the standards of quality normally observed by an entiiy provided such
services to a municipal agency. All services provided shall conform to all federal, state and local
laws, rules and regulations and to the best professional standards and practices. The terms and
conditions set forth in this Agreement shall control over any terms and conditions in Exhibit "A"
to the contrary.
Mike Dering, Service Delivery Manager("City's Project Manager"),shall be the person to
whom Contractor will report for the performance of services hereunder. It is understood that
Contractor's performance hereunder shall be under the supervision of City's Project Manager(or
his%her designee), that Contractor shall coordinate its services hereunder with City's Project
Manager to the extent required by City's Project Manager, and that all performances required
hereunder by Contractor shall be performed to the satisfaction of City's Project Manager and the
City Manager.
2. Compensation and Fees.
a. Contractor's total compensation for all services performed under this
Agreement,shall not exceed FIFTY-TWO THOUSAND THREE HiJNDRED FIFTY DOLLARS
and 00/100($52,350.00)without the prior written authorization of City.
b. The above compensation'shall include all costs, including, but not limited
to, all clerical', administrative, overhead, insurance, reproduction, telephone, travel, auto rental,
subsistence and all related expenses.
c. In addition to the scheduled services to be performed by the Contractor,the
parties recognize that additional, unforeseen work and services may be required by City's Project
Manager. In anticipation of such contingencies,the sum of FIVE THOUSAND TWO HUNDRED
THIRTY-FIVE DOLLARS and 00/100 ($5,235.00) has been added to the total compensation of
this Agreement. City's Project Manager may approve the additional work and the actual costs
incurred by the Contractor in performance of additional work or services in accordance with such
amount as City's Project Manager and the Contractor may agree upon in advance. Said additional
work or services and the amount of compensation therefor, up to the amount of the authorized
contingency, shall be memorialized in the form of an Amendment to Agreement approved by the
City Manager on a form acceptable to the City Attorney. The Contractor agrees to perform only
that work or those services that are specifically requested by the City's Project Manager. Any and
all additional work and services performed under this Agreement shall be completed in such
sequence as to assure their completion as expeditiously as is consistent with professional skill and
care in accordance with a cost estimate or proposal submitted to and approved by City's Project
Manager prior to the commencement of such services.
d. The total amount of compensation under this Agreement, including
contingencies, shall not exceed FIFTY-SEVEN THOUSAND FIVE HUNDRED EIGHTY-FIVE
DOLLARS and 00/100($57,585.00).
3. Pavment.
a. As scheduled services are completed, Contractor shall submit to City an
invoice for the services completed, authorized expenses and authorized extra work actually
performed or incurred.
b. All such invoices shall state the basis for the amount invoiced, including
services completed,the number of hours spent and any extra work performed.
c. City will pay Contractor the amount invoiced within thirty (30) days after
the approval of the invoice.
d. Payment shall,constitute payment in full for all services, authorized costs
and authorized extra work covered by that invoice.
4. ChanEe Orders. No payment for extra services caused by a change in the scope
or complexity of work, or for any other reason, shall be made unless and until such extra services
and a price therefor have been previously authorized in writing and approved by City as an
amendment to this Agreement. City's Project Manager is authorized to approve a reduction in the
services to be performed and compensation therefor. All amendments shall set forth the changes
of work,extension of time,and/or adjustment of the compensation to be paid by City to Contractor
and shall be signed by the City's Project Manager, City Manager or City Council, as applicable.
5. Licenses. Contractor represents that it and any subcontractors it may engage,
possess any and all licenses which are required under state or federal law to perform the work
contemplated by this Agreement and that Contractor and its subcontractors shall mainta.in all
appropriate licenses, including a City of Orange business license, at its cost, during the
performance of this Agreement.
2
6. Indenendent Contractor. At all times during the term of this Agreement,
Contractor shall be an independent contractor and not an employee of City. City shall have the
right to control Contractor only insofar as the result of Contractor's services rendered pursuant to
this Agreement. City shall not have the right to control the means by which Contractor
accomplishes services rendered pursuant to this Agreement. Contractor shall, at its sole cost and
expense, furnish all facilities, materials and equipment which may be required for furnishing
services pursuant to this Agreement. Contractor shall be solely responsible for, and shall
indemnify, defend and save City harmless from all matters relating to the payment of its
subcontractors, agents and employees, including compliance with social security withholding and
all other wages, salaries, benefits, taxes, exactions, and regulations of any nature whatsoever.
Contractor acknowledges that it and any subcontractors, agents or employees employed by
Contractor shall not,under any circumstances,be considered employees of City,and that they shall
not be entitled to any of the benefits or rights afforded employees of City,including,but not limited
to, sick leave, vacation leave, holiday pay, Public Employees Retirement System benefits, or
health, life, dental, long-term disability or workers' compensation insurance benefits.
7. Contractor Not A ent. Except as City may specify in writing, Contractor shall
have no authority, express or implied, to act on behalf of City in any capacity whatsoever as an
agent. Contractor shall have no authority, express or implied, to bind City to any obligation
whatsoever.
8. Designated Persons. Only those qualified persons authorized by City's Project ,
Manager,or as designated in E ibit"A,"shall perform work provided for under this Agreement.
It is understood by the parties that clerical and other nonprofessional work may be performed by
persons other than those designated.
9. Assignment or Subcontractin. No assignment or subcontracting by Contractor
of any part of this Agreement or of funds to be received under this Agreement shall be of any force
or effect unless the assignment has the prior written approval of City. City may terminate this
Agreement rather than accept any proposed assignment or subcontracting. Such assignment or
subcontracting may be approved by the City Manager or his/her designee.
10. Time of Completion. Except as otherwise specified in Exhibit "A," Contractor
shall commence the work provided for in this Agreement within five(5)days of the Effective Date
of this Agreement and diligently prosecute completion of the work as agreed to by and between
the representatives of the parties.
11. Time Is of the Essence. Time is of the essence in this Agreement. Contractor shall
do all things necessary and incidental to the prosecution of Contractor's work.
12. Reserved.
13. Delays and Extensions of Time. Contractor's sole remedy for delays outside its
control, other than those delays caused by City, shall be an extension of time. No matter what the
cause of the delay,Contractor must document any delay and request an extension of time in writing
at the time of the delay to the satisfaction of City. Any extensions granted shall be limited to the
3
length of the delay outside Contractor's control. If Contractor believes that delays caused by City
will cause it to incur additional costs, it must specify, in writing, why the delay has caused
additional costs to be incurred and the exact amount of such cost at the time the delay occurs. No
additional costs can be paid that exceed the not to exceed amount stated in Section 2.a, above,
absent a written amendment to this Agreement.
14. Products of Contractor. The documents, studies, evaluations, assessments,
reports,plans,citations, materials, manuals,technical data, logs, files, designs and other products
produced or provided by Contractor for this Agreement shall become the property of City upon
receipt. Contractor shall deliver all such products to City prior to payment for same. City may
use,reuse or otherwise utilize such products without restriction.
15. Equal Emplovment Onnortunitv. During the performance of this Agreement,
Contractor agrees as follows:
a. Contractor shall not discriminate against any employee or applicant for
employment because of race,color,reiigion, sex,national origin,mental or physical disability,or
any other basis prohibited by applicable law. Contractor shall ensure that applicants are employed,
and that employees are treated during employment, without regard to their race, color, religion,
sex,national origin,mental or physical disability, or any other basis prohibited by applicable law.
Such actions shall include,but not be limited to the following: employment,upgrading,demotion
or transfer,recruitment or recruitment advertising,layoff or termination,rates of pay or other forms
of compensation and selection for training, including apprenticeship. Contractor agrees to post in
conspicuous places, available to employees and applicants for employment, a notice setting forth .
provisions of this non-discrimination clause.
b. Contractor shall, in all solicitations and advertisements for employees
placed by, or on behalf of Contractor, state that all qualified applicants will receive consideration
for employment without regard to race, color, religion, sex, national origin, mental or physical
disability, or any other basis prohibited by applicable law.
c. Contractor shall cause the foregoing paragraphs(a)and(b)to be inserted in
all subcontracts for any work covered by this Agreement, provided that the foregoing provisions
shall not apply to subcontracts for standard commercial supplies or raw materials.
16. Conflicts of Interest. Contractor agrees that it shall not make, participate in the
making,or in any way attempt to use its position as a consultant to influence any decision of City
in which Contractor knows or has reason to know that Contractor, its officers, partners, or
employees have a financial interest as defined in Section 87103 of the Government Code.
Contractor further agrees that it shall not be eligible to work as the design/build firm for the project
that is the subject of this Agreement.
17. Indemnitv.
a. To the fullest extent permitted by law, Contractor agrees to indemnify,
defend and hold City, its City Council and each member thereof,and the officers, officials,agents
4
and employees of City(collectively the"Indemnitees") entirely harmless from all liability arising
out of:
1) Any and all claims under workers' compensation acts and other
employee benefit acts with respect to Contractor's employees or Contractor's subcontractor's
employees arising out of Contractor's work under this Agreement, including any and all claims
under any law pertaining to Contractor or its employees' status as an independent contractor and
any and all claims under Labor Code section 1720 related to the payment of prevailing wages for
public works projects; and
2) Any claim,loss, injury to or death of persons or damage to property
caused by any act, neglect, default, or omission other than a professional act or omission of
Contractor, or person, firm or corporation employed by Contractor, either directly or by
independent contract, including all damages due to loss or theft sustained by any person, firm or
corporation including the Indemnitees, or any of them, arising out of, or in any way connected
with the work or services which are the subject of this Agreement, including injury or damage
either on or off City's property; but not for any loss, injury, death or damage caused by the active
negligence or willful misconduct of City. Contractor, at its own expense, cost and risk, shall
indemnify any and all claims, actions, suits or other proceedings that may be brought or instituted
against the Indemnitees on any such claim or liability covered by this subparagraph, and shall pay
or satisfy any judgment that may be rendered against the Indemnitees, or any of them, in any
action, suit or other proceedings as a result of coverage under this subparagraph.
b. To the fullest extent permitted by law, Contractor agrees to indemnify and
hold Indemnitees entirely harmless from all liability arising out of any claim, loss, injury to or
death of persons or damage to property caused by its negligent professional act or omission in the
performance of professional services pursuant to this Agreement.
c. Except for the Indemnitees, the indemnifications provided in this
Agreement shall not be construed to extend any third party indemnification rights of any kind to
any person or entity which is not a signatory to this Agreement.
d. The indemnities set forth in this section shall survive any closing,
rescission,or termination of this Agreement, and shall continue to be binding and in full force and
effect in perpetuity with respect to Contractor and its successors.
18. Insurance.
a. Contractor shall carry workers' compensation insurance as required by law
for the protection of its employees during the progress of the work. Contractor understands that it
is an independent contractor and not entitled to any workers' compensation benefits under any
City program.
b. Contractor shall maintain during the life of this Agreement the following
minimum amount of comprehensive general liability insurance or commercial general liability
insurance: the greater of (1) One Million Dollars ($1,000,000) per occurrence; or (2) all the
5
insurance coverage and/or limits carried by or available to Contractor. Said insurance shall cover
bodily injury, death and property damage and be written on an occurrence basis.
c. Contractor shall maintain during the life of this Agreement, the following
minimum amount of automotive liability insurance: the greater of(1) a combined single limit of
One Million Dollars ($1,000,000); or (2) all the insurance coverage and/or limits carried by or
available to Contractor. Said insurance shall cover bodily injury, death and property damage for
all owned,non-owned and hired vehicles and be written on an occurrence basis.
d. Any insurance proceeds in excess of or broader than the minimum required
coverage and/or minimum required limits which are applicable to a given loss shall be available
to City. No representation is made that the minimum insurance requirements of this Agreement
are sufficient to cover the obligations of Contractor under this Agreement.
e. Each policy of general liability and automotive liability shall provide that
City, its officers, officials, agents, and employees are declared to be additional insureds under the
terms of the policy, but only with respect to the work performed by Contractor under this
Agreement. A policy endorsement to that effect shall be provided to City along with the certificate
of insurance. In lieu of an endorsement, City will accept a copy of the policy(ies)which evidences
that City is an additional insured as a contracting party. The minimum coverage required by
Subsection 18.b and c, above, shall apply to City as an additional insured.
f.Contractor shall maintain during the life of this Agreement professional
liability insurance covering errors and omissions arising out of the performance of this Agreement
with a minimum limit of One Million Dollars ($1,000,000)per claim. Contractor agrees to keep
such policy in force and effect for at least five (5) years from the date of completion of this
Agreement.
g. The insurance policies maintained by Contractor shall be primary insurance
and no insurance held or owned by City shall be called upon to cover any loss under the policy.
Contractor will determine its own needs in procurement of insurance to cover liabilities other than
as stated above.
h. Before Contractor performs any work or prepares or delivers any materials,
Contractor shall furnish certificates of insurance and endorsements, as required by City,
evidencing the aforementioned minimum insurance coverages on forms acceptable to City,which
shall provide that the insurance in force will not be canceled or allowed to lapse without at least
ten(10) days' prior written notice to City.
i.Except for professional liability insurance coverage that may be required by
this Agreement, all insurance maintained by Contractor shall be issued by companies admitted to
conduct the pertinent line of insurance business in California and having a rating of Grade A or
better and Class VII or better by the latest edition of Best Key Rating Guide. In the case of
professional liability insurance coverage, such coverage shall be issued by companies either
licensed or admitted to conduct business in California so long as such insurer possesses the
aforementioned Best rating.
6
j Contractor shall immediately notify City if any required insurance lapses or
is otherwise modified and cease performance of this Agreement unless otherwise directed by City.
In such a case, City may procure insurance or self-insure the risk and charge Contractor for such
costs and any and all damages resulting therefrom, by way of set-off from any sums owed
Contractor.
k. Contractor agrees that in the event of loss due to any of the perils for which
it has agreed to provide insurance, Contractor shall look solely to its insurance for recovery.
Contractor hereby grants to City,on behalf of any insurer providing insurance to either Contractor
or City with respect to the services of Contractor herein,a waiver of any right to subrogation which
any such insurer may acquire against City by virtue of the payment of any loss under such
insurance.
1.Contractor shall include all subcontractors, if any, as insureds under its
policies or shall furnish separate certificates and endorsements for each subcontractor to City for
review and approval. All coverages for subcontractors shall be subject to all of the requirements
stated herein.
19. Termination. City may for any reason terminate this Agreement by giving
Contractor not less than five (5) days' written notice of intent to terminate. Upon receipt of such
notice, Contractor shall immediately cease work, unless the notice from City provides otherwise.
Upon the termination of this Agreement, City shall pay Contractor for services satisfactorily
provided and all allowable reimbursements incurred to the date of termination in compliance with
this Agreement, unless termination by City shall be for cause, in which event City may withhold
any disputed compensation. City shall not be liable for any claim of lost profits.
20. Maintenance and Inspection of Records. In accordance with generally accepted
accounting principles, Contractor and its subcontractors shall maintain reasonably full and
complete books, documents, papers, accounting records, and other information (collectively, the
records")pertaining to the costs of and completion of services performed under this Agreement.
City and its authorized representatives shall have access to and the right to audit and reproduce
any of Contractor's records regarding the services provided under this Agreement. Contractor shall
maintain all such records for a period of at least three(3)years after termination or completion of
this Agreement. Contractor agrees to make available all such records for inspection or audit at its
offices during normal business hours and upon three(3)days' notice from City,and copies thereof
shall be furnished if requested.
21. Compliance with all Laws/Immi ration Laws.
a. Contractor shall be knowledgeable of and comply with all local, state and
federal laws which may apply to the performance of this Agreement.
b. If the work provided for in this Agreement constitutes a"public works,"as
that term is defined in Section 1720 of the California Labor Code,for which prevailing wages must
be paid, to the extent Contractor's employees will perform any work that falls within any of the
7
classifications for which the Department of Labor Relations of the Sta.te of California promulgates
prevailing wage determinations, Contractor hereby agrees that it, and any subcontractor under it,
shall pay not less than the specified prevailing rates of wages to all such workers. The general
prevailing wage determinations for crafts can be located on the website of the Department of
Industrial Relations (www.dir.ca.gov/DLSR). Additionally, to perform work under this
Agreement,Contractor must meet all State registration requirements and criteria,including project
compliance monitoring.
c. Contractor represents and warrants that Contractor:
1) Has complied and shall at all times during the term of this
Agreement comply, in all respects, with all immigration laws, regulations, statutes, rules, codes,
and orders, including, without limitation, the Immigration Reform and Control Act of 1986
IRCA); and
2) Has not and will not knowingly employ any individual to perform
services under this Agreement who is ineligible to work in the United States or under the terms of
this Agreement;.and
3) Has properly maintained, and shall at all times during the term of
this Agreement properly maintain, all related employment documentation records including,
without limitation, the completion and maintenance of the Form I-9 for each of Contractor's
employees; and
4) Has responded, and shall at all times during the term of this
Agreement respond, in a timely fashion to any government inspection requests relating to
immigration law compliance and/or Form I-9 compliance and/or worksite enforcement by the
Department of Homeland Security, the Department of Labor, or the Social Security
Administration.
d. Contractor shall require all subcontractors or subconsultants to make the
same representations and warranties as set forth in Subsection 21.c.
e. Contractor shall, upon request of City, provide a list of all employees
working under this Agreement and shall provide,to the reasonable satisfaction of City,verification
that all such employees are eligible to work in the United States. All costs associated with such
verification shall be borne by Contractor. Once such request has been made, Contractor may not
change employees working under this Agreement without written notice to City, accompanied by
the verification required herein for such employees.
f.Contractor shall require all subcontractors or sub-consultants to make the
same verification as set forth in Subsection 21.e.
g. If Contractor or subcontractor knowingly employs an employee providing
work under this Agreement who is not authorized to work in the United States, and/or fails to
8
follow federal laws to determine the status of such employee,that shall constitute a material breach
of this Agreement and may be cause for immediate termination of this Agreement by City.
h. Contractor agrees to indemnify and hold City, its officers, officials, agents
and employees harmless for,of and from any loss, including but not limited to fines,penalties and
corrective measures City may sustain by reason of Contractor's failure to comply with said laws,
rules and regulations in connection with the performance of this Agreement.
22. Governin Law and Venue. This Agreement shall be construed in accordance
with and governed by the laws of the State of California and Contractor agrees to submit to the
jurisdiction of California courts. Venue for any dispute arising under this Agreement shall be in
Orange County, California.
23. Intesration. This Agreement constitutes the entire agreement of the parties. No
other agreement,oral or written,pertaining to the work to be performed under this Agreement shall
be of any force or effect unless it is in writing and signed by both parties. Any work performed
which is inconsistent with or in violation of the provisions of this Agreement shall not be
compensated.
24. Notice. Except as otherwise provided herein, all notices required under this
Agreement shall be in writing and delivered personally, by e-mail, or by first class U.S. mail,
postage prepaid, to each party at the address listed below. Either party may change the notice
address by notifying the other party in writing. Notices shall be deemed received upon receipt of .
same or within three(3) days of deposit in the U.S.Mail,whichever is earlier. Notices sent by e-
mail shall be deemed received on the date of the e-mail transmission.
CONTRACTOR" CITY"
Triad Consulting&System Design Group,LLC City of Orange
2925 Mira Vista Way, 300 E. Chapman Avenue
Corona, CA 92881 Orange, CA 92866-1591
Attn.: Gregory Brandon Attn.: Mike Dering
Telephone No.: 949-943-9422 Telephone No.: 714-744-2285
E-Mail: gbrandon@triadsdg.com E-Mail: mdering@cityoforange.org
25. Counternarts. This Agreement may be executed in one or more counterparts,each
of which shall be deemed an original, but all of which together shall constitute one and the same
instrument. Signatures transmitted via facsimile and electronic mail shall have the same effect as
original signatures.
Remainder of page intentionally left blank; signatures on next page]
9
IN WITNESS of this Agreement, the parties have entered into this Agreement as of the
year and day first above written.
CONTRACTOR" CITY"
TRIAD CONSULTING& SYSTEM CITY OF ORANGE,a municipal corporation
DESIGN GROUP,LLC, a California
limited 1' bility company
By; C S . ,La,.,,,,,, By;
Printed me:t v w 13,2.,,, Mark A. rphy,Mayor
Title: t'r c,,A L
By:
Printed Name:
Title: c o r ATTEST:
Pamela Coleman, City Clerk
APPROVED AS TO FORM:
Mary E.Bi ing, Sr.Assistan i Attorney
NOTE:City requires the following signature(s)on behalf of the Contractor:
1)the Chairman of the Board,the President or a Vice-President,AND(2)the
Secretary, the Chief Financial Officer, the Treasurer, an Assistant Secretary
or an Assistant Treasurer. If only one corporate officer egists or one corporate
officer holds more than one corporate office,please so indicate. OR
The corporate officer named in a corporate resolution as authorized to enter
into this Agreement. A copy of the corporate resolution, certified by the
Secretary close in time to the ezecution of the Agreement,must be provided to
City.
10
EXHIBIT"A"
SCOPE OF SERVICES
Beneath this sheet.]
TRIAI CONSULTIi TG
SYSTEM DESIGN GROUP
October 26`,2020
Michael Dering,PMP
City of Orange
Information Technology Project Manager
300 E.Chapman Ave
Orange,CA 92866
Subject: Security Consulting&Desigri Services For;
City of Orange Intrusion Alarm&Fire Alarm Assessments and Recommendation
Michael:
This proposal is for security consulting services for City of Orange: Intrusion Alarm/Fire System
assessment and recommendation for improvements and design
Based on our meeting/discussion and information received on the twenty-three(23)sites The
information contained herein outlines the scope and fee of Triad Consulting services for the City by
Phase: (I)assess the existing alarm and fire alarm panels at the list below locations for assessments and
integration of alann panels into the Genetec Security Center platform,design alarm panel and device
locations to meet the specific needs of each site,assess the existing fire panel for monitoring and call out
capabilities(II)construction support service during system installation and(III) ongoing manages
services T&M(optional)
Alarm Intrusion/Fire Monitoring at the following locations:
Civic Basement Civic Human Resources
Computer Deck/Finance/Admin -CY Garage Bldg. 1
Cy Warehouse Bldg.2 East End Substation
El Camino El Modena Library/OCPT
Fire Station 3 Fire Station 4
Fire Station 6 Fire Station 7
Fire Station 8 Fire HQ
Grijalva Park Gym Hart Pazk
Main Library Metro Tunnel
ODP Barn Pitcher Park
Senior Citizens Center Taft
Water Yard
2925 Mira Vista Way
Corona 92881
Phone: 949-943-9422
TRIAD CONSULTIIoTG
SYSTEM DESIGN GROUP
Phase I Alarm System Design
1. Development of Construction Documents
a. Meetings with City of Orange key stalceholders to discuss system
requirements and operation at each location
b. Request site plan and building plans for documentation of existing system
if available)
c. Conduct a detailed site survey of existing alarm&fire alarm panels and
edge device location
d. Site survey shall include review of security devices,fire alarm panels
document existing security devices on drawing and make design
recommendations for improvement to integrate alarm functions into the
Genetec Security Center platform.
e. Survey the e sting fire alann panel for system monitoring and make
recommendation for improvements if necessary
f. Survey to include twenty-three locations to determine how these sites can
be upgraded and connected to the Genetec Security Center platform.
g. Verify IDF rooms space requirement and wiring configuration.
h. Prepare fully integrated specifications and drawings in AutoCAD 19 or
later format.Drawings will include:title sheet,floor plans,details and
single-line diagrams for the security alarm system only (this in not a fire
alarm system design),Information on the drawings shall include
architectural backgrounds,control panel locations,phasing plans if
required,new security device locations where required,wiring connection
details and connection to existing power sources.
i. Coordinate specifications with City standard contract requirements to
ensure there are no conflicts.
j. Deliver 95%design documents and ROM costs for review and comment.
k. Update 95%design documents to incorporate review comments and
prepare for incorporation to City bid documents. Update ROM costs as
needed based on review comments.
II. Phase II Construction Administration
1. Installation Oversite
a. Attend contractor kick-off ineeting
b. Review drawings and material submittal package for compliance with
contract requirements
c. Review and respond to contractor requests for information
d. Attend site visit and coordination conference calls
2925 Mira Vista Way
Cornna 92881
Phone: 949-943-9422
TRIAD CONSULTING
SYSTEM DESIGN GROUP
e. Monitor system installation to include contractor submittal review,
progress meetings,meeting notes and periodic on-site installation reviews.
f. Provide punch list near substantial completion with one follow up punch
list at completion(if required)
g. Acceptance Testing: Witness final acceptance testing with one follow-up
test(if required).Additional tests due to improper system configuration or
incomplete installation at time of schedule final test will be treated as
additional services.
h. Review as-built documentation produced by the contractor for
completeness.
III. Phase III Managed Services
1. Added Value—Ongoing Support
a. Run system reports and identify any system anomalies. Coordinate with
Genetec technical support to bring system into normal operating
parameters.
b. Upon completion of repair or correction of all system anomalies run
baseline reports to document normal system operation.
c. Conduct(weekly/bi-weekly/monthly)site visits. Run reports to make
sure the system is operating within the baseline parameters. Identify any
system anomalies and correct if possible or recommend method of
correction.
d. Coordinate with the City Deparhnent for any system programming
modifications to enhance system operation for personnel monitoring the
system.
e. Make recommendations as identified that may provide an enhanced level
of operation for the Security Department to fulfill their responsibilities
IV. FEE
A. Based on the Scope of Work described herein,proposed fees including reimbursable
expenses:
1. Phase I Construction Documents 33,890.00
2. Phase II Construction Administration 18 460.00
Total 52,350.00
2925 Mira Vista Way
Corona 92881
Phone: 949-943-9422
TRIAD CONSULTI.I TG
SYSTEM DESIGN GROUP
3. Phase IV Managed Services 170.00 Hourly Rate
B. Triad will bill monthly for supplemental services for actual time spent according to the
following standard hourly rates.
C.
PROFESSIONAL FEES(PER HOUR)
Principal 210
Senior Security Consultant 175
Project Manager 175
Sr Project Engineer 170
Project Designer 110
Project Coordinator 100
Computer Design Specialist 90
Administration 65
Sincerely,
itl .V,,,,r,,,,vl..,
Gregory Brandon
PrincipaUOwner
Triad Consulting&System Design Group
2925 Mira Vista Way
Corona 92881
Phone: 949-943-9422