AGR-7414 - RKLJS CORP DBA SO CAL LIGHTING PROSagIR-rlL\
PROFESSIONAL SERVICES AGREEMENT
Storage,Installation and Removal of Holiday Lighting]
THIS PROFESSIONAL SERVICES AGREEMENT (the "Agreement") is made at
Orange, California, on this 36144day of A&3(A 2022 (the "Effective Date") by and
among the CITY OF ORANGE, a municipal corporation ("City"), and RKLJS CORP, a
California corporation, dba SO CAL LIGHTING PROS ("the Contractor"),who agree as follows:
1. Services. Subject to the terms and conditions set forth in this Agreement, Contractor
shall provide to the reasonable satisfaction of City the services set forth in Exhibit "A," which is
attached hereto and incorporated herein by reference. As a material inducement to City to enter into
this Agreement, Contractor represents and warrants that it has thoroughly investigated and
considered the scope of services and fully understands the difficulties and restrictions in performing
the work. The services which are the subject of this Agreement are not in the usual course of City's
business and City relies on Contractor's representation that it is independently engaged in the
business of providing such services and is experienced in performing the work. Contractor shall
perform all services in a manner reasonably satisfactory to City and in a manner in conformance
with the standards of quality normally observed by an entity provided such services to a municipal
agency. All services provided shall conform to all federal, state and local laws, rules and
regulations and to the best professional standards and practices. The terms and conditions set forth
in this Agreement shall control over any terms,and conditions in Exhibit"A" to the contrary.
Paul Miller, Parks Supervisor ("City's Project Manager"), shall be the person to whom
Contractor will report for the performance of services hereunder. It is understood that Contractor's
performance hereunder shall be under the supervision of City's Project Manager(or designee), that
Contractor shall coordinate its services hereunder with City's Project Manager to the extent
required by City's Project Manager, and that all performances required hereunder by Contractor
shall be performed to the satisfaction of City's Project Manager and the City Manager.
2. Compensation and Fees.
a. Contractor's total compensation for all services performed under this Agreement,
including reimbursable costs and expenses) for the 2022 holiday season shall be a base fee of
EIGHTEEN THOUSAND FIVE HUNDRED SIXTY-TWO DOLLARS and 72/100
18,562.72), with a contingency for additional costs in the amount of ONE THOUSAND EIGHT
HUNDRED FIFTY-SIX DOLLARS and 28/100 ($1,856.28), without the written authorization of
the City. The total not to exceed amount for the holiday seasons for this agreement shall not exceed
TWENTY THOUSAND FOUR HUNDRED EIGHTEEN and 99/100 ($20,418.99) without the
prior written authorization of City.
b. The above compensation shall include all costs, including, but not limited to, all
clerical, administrative, overhead, insurance, reproduction, telephone, travel, auto rental,
subsistence and all related expenses.
3.Payment.
a. Payment shall be,made as follows:
3. Payment.
a. Payment shall be made as follows:
Fifty percent(50%)-$9,281.36— payable upon execution of the Agreement by City.
Fifty percent(50%)-$9,281.36— payable within thirty(30) days after satisfactory
completion of the work and acceptance by City.The final
invoice shall include any authorized additional amounts.
b. All such invoices shall state the basis for the amount invoiced, including
services completed and any extra work performed.
c. Payment shall constitute payment in full for all services, authorized costs
and authorized extra work covered by that invoice.
4. Change Orders. No payment for extra services caused by a change in the scope
or complexity of work, or for any other reason, shall be made unless and until such extra services
and a price therefor have been previously authorized in writing and approved by City as an
amendment to this Agreement. City's Project Manager is authorized to approve a reduction in the
services to be performed and compensation therefor. All amendments shall set forth the changes
of work,extension of time,and/or adjustment of the compensation to be paid by City to Contractor
and shall be signed by the City's Project Manager, City Manager or City Council, as applicable.
5. Licenses. Contractor represents that it and any subcontractors it may engage,
possess any and all licenses which are required under state or federal law to perform the work
contemplated by this Agreement and that Contractor and its subcontractors shall maintain all
appropriate licenses, including a City of Orange business license, at its cost, during the
performance of this Agreement.
6. Independent Contractor. At all times during the term of this Agreement,
Contractor shall be an independent contractor and not an employee of City. City shall have the
right to control Contractor only insofar as the result of Contractor's services rendered pursuant to
this Agreement. City shall not have the right to control the means by which Contractor
accomplishes services rendered pursuant to this Agreement. Contractor shall, at its sole cost and
expense, furnish all facilities, materials and equipment, which may be required for furnishing
services pursuant to this Agreement. Contractor shall be solely responsible for, and shall
indemnify, defend and save City harmless from all matters relating to the payment of its
subcontractors,agents and employees,including compliance with social security,withholding and
all other wages, salaries, benefits, taxes, exactions, and regulations of any nature whatsoever.
Contractor acknowledges that Contractor and any subcontractors, agents or employees employed
by Contractor shall not, under any circumstances, be considered employees of City, and that they
shall not be entitled to any of the benefits or rights afforded employees of City, including,but not
limited to, sick leave,vacation leave,holiday pay, Public Employees Retirement System benefits,
or health, life, dental,long-term disability or workers' compensation insurance benefits.
2
7. Contractor Not Agent. Except as City may specify in writing, Contractor shall
have no authority, express or implied, to act on behalf of City in any capacity whatsoever as an
agent. Contractor shall have no authority, express or implied, to bind City to any obligation
whatsoever.
8. Designated Persons. Only those qualified persons authorized by City's Project
Manager, or as designated in Exhibit"A,"shall perform work provided for under this Agreement.
It is understood by the parties that clerical and other nonprofessional work may be performed by
persons other than those designated.
9. Assignment or Subcontracting. No assignment or subcontracting by Contractor
of any part of this Agreement or of funds to be received under this Agreement shall be of any force
or effect unless the assignment has the prior written approval of City. City may terminate this
Agreement rather than accept any proposed assignment or subcontracting. Such assignment or
subcontracting may be approved by the City Manager or his/her designee.
10. Time of Completion. Installation shall start no earlier than November 21, 2022
and shall be completed no later than November 27, 2022. In addition, removal shall begin no
earlier than January 2, 2023, and shall be completed no later than January 9, 2023.
11. Time Is of the Essence. Time is of the essence in this Agreement. Contractor shall
do all things necessary and incidental to the prosecution of Contractor's work.
12. Reserved.
13. Delays and Extensions of Time. Contractor's sole remedy for delays outside its
control, other than those delays caused by City, shall be an extension of time. No matter what the
cause of the delay,Contractor must document any delay and request an extension of time in writing
at the time of the delay to the satisfaction of City. Any extensions granted shall be limited to the
length of the delay outside Contractor's control. If Contractor believes that delays caused by City
will cause it to incur additional costs, it must specify, in writing, why the delay has caused
additional costs to be incurred and the exact amount of such cost at the time the delay occurs. No
additional costs can be paid that exceed the not to exceed amount stated in Section 2.a, above,
absent a written amendment to this Agreement.
14. Products of Contractor. The documents, studies, reports, plans, citations,
materials, manuals and other products produced or provided by Contractor for this Agreement
shall become the property of City upon receipt. Contractor shall deliver all such products to City
prior to payment for same. City may use, reuse or otherwise utilize such products without
restriction.
15. Equal Employment Opportunity. During the performance of this Agreement,
Contractor agrees as follows:
a. Contractor shall not discriminate against any employee or applicant for
employment because of race, color, religion, sex, national origin,mental or physical disability, or
3
any other basis prohibited by applicable law. Contractor shall ensure that applicants are employed,
and that employees are treated during employment, without regard to their race, color, religion,
sex,national origin, mental or physical disability, or any other basis prohibited by applicable law.
Such actions shall include,but not be limited to the following: employment,upgrading, demotion
or transfer,recruitment or recruitment advertising,layoff or termination,rates of pay or other forms
of compensation and selection for training, including apprenticeship. Contractor agrees to post in
conspicuous places, available to employees and applicants for employment, a notice setting forth
provisions of this non-discrimination clause.
b. Contractor shall, in all solicitations and advertisements for employees
placed by, or on behalf of Contractor, state that all qualified applicants will receive consideration
for employment without regard to race, color, religion, sex, national origin, mental or physical
disability, or any other basis prohibited by applicable law.
c. Contractor shall cause the foregoing paragraphs(a)and(b)to be inserted in
all subcontracts for any work covered by this Agreement, provided that the foregoing provisions
shall not apply to subcontracts for standard commercial supplies or raw materials.
16. Conflicts of Interest. Contractor agrees that it shall not make, participate in the
making, or in any way attempt to use its position as a contractor to influence any decision of City
in which Contractor knows or has reason to know that Contractor, its officers, partners, or
employees have a financial interest as defined in Section 87103 of the Government Code.
17. Indemnity.
a. To the fullest extent permitted by law, Contractor agrees to indemnify,
defend and hold City,its City Council and each member thereof, and the officers, officials, agents
and employees of City(collectively the"Indemnitees")entirely harmless from all liability arising
out of:
1) Any and all claims under workers' compensation acts and other
employee benefit acts with respect to Contractor's employees or Contractor's subcontractor's
employees arising out of Contractor's work under this Agreement, including any and all claims
under any law pertaining to Contractor or its employees' status as an independent contractor and
any and all claims under Labor Code section 1720 related to the payment of prevailing wages for
public works projects; and
2) Any claim,loss,injury to or death of persons or damage to property
caused by any act, neglect, default, or omission other than a professional act or omission of
Contractor, or person, firm or corporation employed by Contractor, either directly or by
independent contract, including all damages due to loss or theft sustained by any person, firm or
corporation including the Indemnitees, or any of them, arising out of, or in any way connected
with the work or services which are the subject of this Agreement, including injury or damage
either on or off City's property;but not for any loss, injury, death or damage caused by the active
negligence or willful misconduct of City. Contractor, at its own expense, cost and risk, shall
indemnify any and all claims, actions, suits or other proceedings that may be brought or instituted
4
against the Indemnitees on any such claim or liability covered by this subparagraph, and shall pay
or satisfy any judgment that may be rendered against the Indemnitees, or any of them, in any
action, suit or other proceedings as a result of coverage under this subparagraph.
b. To the fullest extent permitted by law, Contractor agrees to indemnify and
hold Indemnitees entirely harmless from all liability arising out of any claim, loss, injury to or
death of persons or damage to property caused by its negligent professional act or omission in the
performance of professional services pursuant to this Agreement.
c. Except for the Indemnitees, the indemnifications provided in this
Agreement shall not be construed to extend any third party indemnification rights of any kind to
any person or entity which is not a signatory to this Agreement.
d. The indemnities set forth in this section shall survive any closing,
rescission,or termination of this Agreement,and shall continue to be binding and in full force and
effect in perpetuity with respect to Contractor and its successors.
18. Insurance.
a. Contractor shall carry workers' compensation insurance as required by law
for the protection of its employees during the progress of the work. Contractor understands that it
is an independent contractor and not entitled to any workers' compensation benefits under any
City program.
b. Contractor shall maintain during the life of this Agreement the following
minimum amount of comprehensive general liability insurance or commercial general liability
insurance: the greater of (1) One Million Dollars ($1,000,000) per occurrence; or (2) all the
insurance coverage and/or limits carded by or available to Contractor. Said insurance shall cover
bodily injury, death and property damage and be written on an occurrence basis.
c. Contractor shall maintain during the life of this Agreement, the following
minimum amount of automotive liability insurance: the greater of (1) a combined single limit of
One Million Dollars ($1,000,000) or (2) all the insurance coverage and/or limits carried by or
available to Contractor. Said insurance shall cover bodily injury, death and property damage for
all owned, non-owned and hired vehicles and be written on an occurrence basis.
d. Any insurance proceeds in excess of or broader than the minimum required
coverage and/or minimum required limits which are applicable to a given loss shall be available
to City. No representation is made that the minimum insurance requirements of this Agreement
are sufficient to cover the obligations of Contractor under this Agreement.
e. Each policy of general liability and automotive liability shall provide that
City, its officers, officials, agents, and employees are declared to be additional insureds under the
terms of the policy, but only with respect to the work performed by Contractor under this
Agreement. A policy endorsement to that effect shall be provided to City along with the certificate
of insurance. In lieu of an endorsement, City will accept a copy of the policy(ies)which evidences
5
compliance with this Agreement,unless termination by City shall be for cause,in which event City
may withhold any disputed compensation. City shall not be liable for any claim of lost profits.
20. Maintenance and Inspection of Records. In accordance with generally accepted
accounting principles, Contractor and its subcontractors shall maintain reasonably full and
complete books, documents, papers, accounting records, and other information (collectively, the
records")pertaining to the costs of and completion of services performed under this Agreement.
City and its authorized representatives shall have access to and the right to audit and reproduce
any of Contractor's records regarding the services provided under this Agreement. Contractor shall
maintain all such records for a period of at least three (3)years after termination or completion of
this Agreement. Contractor agrees to make available all such records for inspection or audit at its
offices during normal business hours and upon three(3)days' notice from City,and copies thereof
shall be furnished if requested.
21. Compliance with all Laws/Immigration Laws.
a. Contractor shall be knowledgeable of and comply with all local, state and
federal laws which may apply to the performance of this Agreement.
b. If the work provided for in this Agreement constitutes a"public works,"as
that term is defined in Section 1720 of the California Labor Code,for which prevailing wages must
be paid, to the extent Contractor's employees will perform any work that falls within any of the
classifications for which the Department of Labor Relations of the State of California promulgates
prevailing wage determinations, Contractor hereby agrees that it, and any subcontractor under it,
shall pay not less than the specified prevailing rates of wages to all such workers. The general
prevailing wage determinations for crafts can be located on the website of the Department of
Industrial Relations (www.dir.ca.gov/DLSR). Additionally, to perform work under this Contract,
Contractor must meet all State registration requirements and criteria,including project compliance
monitoring.
c. Contractor represents and warrants that Contractor:
1) Has complied and shall at all times during the term of this
Agreement comply, in all respects, with all immigration laws, regulations, statutes, rules, codes,
and orders, including, without limitation, the Immigration Reform and Control Act of 1986
IRCA); and
2) Has not and will not knowingly employ any individual to perform
services under this Agreement who is ineligible to work in the United States or under the terms of
this Agreement; and
3) Has properly maintained, and shall at all times during the term of
this Agreement properly maintain, all related employment documentation records including,
without limitation, the completion and maintenance of the Form I-9 for each of Contractor's
employees; and
7
that City is an additional insured as a contracting party. The minimum coverage required by
Subsection 18.b and c, above, shall apply to City as an additional insured.
f.Reserved.
g. The insurance policies maintained by Contractor shall be primary insurance
and no insurance held or owned by City shall be called upon to cover any loss under the policy.
Contractor will determine its own needs in procurement of insurance to cover liabilities other than
as stated above.
h. Before Contractor performs any work or prepares or delivers any materials,
Contractor shall furnish certificates of insurance and endorsements, as required by City,
evidencing the aforementioned minimum insurance coverages on forms acceptable to City,which
shall provide that the insurance in force will not be canceled or allowed to lapse without at least
ten(10) days' prior written notice to City.
i.All insurance maintained by Contractor shall be issued by companies
admitted to conduct the pertinent line of insurance business in California and having a rating of
Grade A or better and Class VII or better by the latest edition of Best Key Rating Guide. In the
case of professional liability insurance coverage, such coverage shall be issued by companies
either licensed or admitted to conduct business in California so long as such insurer possesses the
aforementioned Best rating.
j Contractor shall immediately notify City if any required insurance lapses or
is otherwise modified and cease performance of this Agreement unless otherwise directed by City.
In such a case, City may procure insurance or self-insure the risk and charge Contractor for such
costs and any and all damages resulting therefrom, by way of set-off from any sums owed
Contractor.
k. Contractor agrees that in the event of loss due to any of the perils for which
it has agreed to provide insurance, Contractor shall look solely to its insurance for recovery.
Contractor hereby grants to City, on behalf of any insurer providing insurance to either Contractor
or City with respect to the services of Contractor herein,a waiver of any right to subrogation which
any such insurer may acquire against City by virtue of the payment of any loss under such
insurance.
1.Contractor shall include all subcontractors, if any, as insureds under its
policies or shall furnish separate certificates and endorsements for each subcontractor to City for
review and approval. All coverages for subcontractors shall be subject to all of the requirements
stated herein.
19. Termination. City may for any reason terminate this Agreement by giving the
Contractor not less than five (5) days' written notice of intent to terminate. Upon receipt of such
notice, the Contractor shall immediately cease work, unless the notice from City provides
otherwise. Upon the termination of this Agreement, City shall pay Contractor for services
satisfactorily provided and all allowable reimbursements incurred to the date of termination in
6
4) Has responded, and shall at all times during the term of this
Agreement respond, in a timely fashion to any government inspection requests relating to
immigration law compliance and/or Form I-9 compliance and/or worksite enforcement by the
Department of Homeland Security, the Department of Labor, or the Social Security
Administration.
d. Contractor shall require all subcontractors or subconsultants to make the
same representations and warranties as set forth in Subsection 21.c.
e. Contractor shall, upon request of City, provide a list of all employees
working under this Agreement and shall provide,to the reasonable satisfaction of City,verification
that all such employees are eligible to work in the United States. All costs associated with such
verification shall be borne by Contractor. Once such request has been made, Contractor may not
change employees working under this Agreement without written notice to City, accompanied by
the verification required herein for such employees.
f.Contractor shall require all subcontractors or sub-consultants to make the
same verification as set forth in Subsection 21.e.
g. If Contractor or subcontractor knowingly employs an employee providing
work under this Agreement who is not authorized to work in the United States, and/or fails to
follow federal laws to determine the status of such employee,that shall constitute a material breach
of this Agreement and may be cause for immediate termination of this Agreement by City.
h. Contractor agrees to indemnify and hold City, its officers, officials, agents
and employees harmless for, of and from any loss,including but not limited to fines,penalties and
corrective measures City may sustain by reason of Contractor's failure to comply with said laws,
rules and regulations in connection with the performance of this Agreement.
22. Governing Law and Venue. This Agreement shall be construed in accordance
with and governed by the laws of the State of California and Contractor agrees to submit to the
jurisdiction of California courts. Venue for any dispute arising under this Agreement shall be in
Orange County, California.
23. Integration. This Agreement constitutes the entire agreement of the parties. No
other agreement,oral or written,pertaining to the work to be performed under this Agreement shall
be of any force or effect unless it is in writing and signed by both parties. Any work performed
which is inconsistent with or in violation of the provisions of this Agreement shall not be
compensated.
24. Notice. Except as otherwise provided herein, all notices required under this
Agreement shall be in writing and delivered personally, by e-mail, or by first class U.S. mail,
postage prepaid, to each party at the address listed below. Either party may change the notice
address by notifying the other party in writing. Notices shall be deemed received upon receipt of
same or within three (3) days of deposit in the U.S. Mail,whichever is earlier. Notices sent by e-
mail shall be deemed received on the date of the e-mail transmission.
8
CONTRACTOR" CITY"
So Cal Lighting Pros City of Orange
5348 Bullpen Dr. 300 E. Chapman Avenue
Fontana CA 92336 Orange, CA 92866-1591
Attn.: Rahn Sidebotham Attn.: Paul Miller
Telephone No.: (805) 203-9995 Telephone No.: 714-532-6472
E-Mail Address: Rahn@socallightingpros.com E-Mail Address: pmiller()cityoforange.org
26. Counterparts. This Agreement may be executed in one or more counterparts,each
of which shall be deemed an original, but all of which together shall constitute one and the same
instrument. Signatures transmitted via facsimile and electronic mail shall have the same effect as
original signatures.
IN WITNESS of this Agreement, the parties have entered into this Agreement as of the
year and day first above written.
CONTRACTOR" CITY"
RKLJS CORP, a California corporation,CITY OF ORANGE, a municipal corporation
dba SO CAL LIGHTING PROS
B l+Y:Y
Print e: 1241N Rob Houston, City Manager
Title: ?Tel-, ekew
By: APPROVED AS TO FORM:
Print e: r
Title: C IktrkAthe- COc (4'ieMDMaryE. Bi i
Senior Assistant City Attorney
NOTE: City requires the following signature(s)on behalf of the Contractor:
1)the Chairman of the Board,the President or a Vice-President,AND(2)the Secretary,
the Chief Financial Officer, the Treasurer, an Assistant Secretary or an Assistant
Treasurer. If only one corporate officer exists or one corporate officer holds more than
one corporate office,please so indicate. OR
The corporate officer named in a corporate resolution as authorized to enter into this
Agreement. A copy of the corporate resolution, certified by the Secretary close in time
to the execution of the Agreement,must be provided to City.
9
EXHIBIT "A"
SCOPE OF SERVICES
Beneath this sheet.]
Y
Job# 1640
SO CAL LIGHTING PROS
EXHIBIT "A"
Scope of Services
This contract entered into by and between SO CAL LIGHTING PRO'S (herein after
Installer") and City of Orange (herein after "Customer"). Witnessed that the parties
hereto do mutually agree as follows:
1. TERM OF CONTRACT
The term of this Contract schedule, with respect to each item of installation listed
here in;(18)- 66' traditional tri candle wreaths skylines (1)- 30' Oregon cascade tree
with holiday ornaments (1) 6' tree topper (1) 15' santa (1)- 17' toy soldier, is for a
term of 12 months. Commencing August 2022
2. STATEMENT OF WORK
Installer shall install, remove and store decorations for customer. Location of
installation: City of Orange 230 E. Chapman Ave. Orange, CA
92866-1506. Installation shall be started not earlier than November 21, 2022 and
must be completed no later than November 27,2022. Removal shall be started no
earlier than January 2, 2023 and completed no later than January 9, 2023. Installer
shall not be liable for delays of installation or removal of decorations caused by
weather, fires, acts of God, or civil unrest, to include protesting looting, or rioting, or
the blocking of any routes of travel or entry onto the jobsite from the Installers place
of business to the work location.
3. PAYMENTS
Customer shall pay to installer for the performance of this contract a price of
18,562.72 which includes a fuel surcharge of which shall constitute total
compensation to Installer. Installer is under no obligation for performance of this
Contract unless executed Contract is returned and payment is made by the payment
due date. Payments made after 30 days of the second invoice will incur a 3%
interest penalty-compounding monthly.
PAYMENT SHALL BE AS FOLLOWS:
50% $ 9281.36 due upon receipt of Contract, prior to installation
50% $ 9281.36 due upon receipt or within 30 days of 2' invoice.
4. WARRANTY
Installer warrants all work shall be performed in a work-manlike manner. Except for
the warranty of performance in a work-manlike manner, Installer makes no other
warranties, expressed or implied. In any event, Installer shall not be responsible or
liable for loss of decorations cause by any reason whatsoever, including but not
limited to: theft, fire, vandalism, civil unrest, looting, rioting, wind exceeding 30
M.P.H. or any act of God.
5. PRODUCT DISPOSAL
Job# 1640
Upon cancellation of contract, Customer will be responsible for disposal of their
product. Customer shall notify Installer 48 hours before picking up their product or
pay Installer to dispose of product.
6. INSURANCE
Installer shall obtain a policy of insurance insuring Installer and Customer against
liability for loss suffered by third parties with respect to the installation of said
decorations in the amount of$1,000,000.00. Installer will provide Customer with
proof of insurance, if requested by Customer, at no charge. Customers may be
added as additional insured upon request at no charge.Any and all other insurance
required by law or by the Customer shall be the Customer's sole Responsibility.
7. SITE PREPARATION AND PLOT PLAN
The location for the Installation of the decorations shall be furnished by customer
and must first be approved by Installer or its representative as to feasibility for
installation. Customer will be responsible for securing any permission, permits, and
licenses necessary for proper installation of decorations from owners, lessees,
lessors, city, state and other governmental authority. Customers will be responsible
for all necessary fees. Installer is given permission to install decoration hardware
items including but not limited to faceplates, cables, and anchor points within a
reasonable time prior to actual installation dates. All hardware items will be left in
place between seasons. Customer is responsible to ensure light standers,or poles
are in good repair and ready for use.
8. ELECTRICAL SOURCE AND CURRENT
Customer shall furnish adequate electrical power and suitable electrical connections
as are customarily used in the electrical trade or required by Underwriter's
Laboratory within a reasonable area, not to exceed 8 feet of the decoration
installation site, for distance greater than 8 feet Customer will be charged for
extension cords. To be billed with second installment. Customer warrants that the
electrical connection supplied shall be suitable for the intended purpose. Customer
shall be responsible for payment for electric current consumed by decorations.
9. SUBCONTRACTORS AND ASSIGNMENTS
Installers have the option to assign all or part of its rights and obligations under the
terms of this Contract.Any such assignment shall not relieve Customer of its duty of
performance under any of the terms or conditions of this Contract.
10. CONFLICT OF APPLICABLE LAW
If any paragraph or provision of this Contract is declared contrary to public policy
unenforceable in law or equity, then in that event, that portion shall be deleted from
this Contract, and remaining portions shall remain in full force and effect.
11. DEFAULT
In the event of a default of any payment of any sums due hereunder, or in the
performance of any other covenant herein, and if customer fails to cure said default
within three (3) days after written notice from Installer, or if Customer becomes
insolvent, or ceases to do business as a going concern, or makes an assignment for
the benefit of creditors or any proceeding or petition under the Bankruptcy Act as
Job# 1640
amended is filed by or against customer, (including a proceeding for reorganization,
arrangement, or extension) then in such event, Installer at it's sole option shall have
the right to terminate this contract as to any and all items of installation, and Installer
shall thereupon by entitled to recover from customer the excess, if any, of the
amount of payments reserved in the Contract for the balance of the stated term.
12. SERVICE CALLS
There will be no charge for Service Calls, after decorations are installed, for an
installation related problem. Problems not related to installation including but not
limited to vandalism, weather, civil unrest, looting, protesting, rioting, or acts of God.
In the event the problem is not related to installation Installer will charge Customer
an additional $80.00 per hour including travel time. If adequate power or proper
electrical connections are not available at installation site at the time of installation
and Customer wishes Installer to return to the installation site to connect the
electrical at a later date there will be an additional charge of$80.00 per hour
including travel time.
13. ADDITIONAL TERMS
None.
SO CAL LIGHTING PROS
5348 Bullpen Dr.
Fontana CA 92336
Rahn@socallightingpros.com