AGR-7468 - STANTEC CONSULTING SERVICES INCDocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31 CDs
AGR-7468 C
PROFESSIONAL SERVICES AGREEMENT
Hydraulic Model Analysis Services]
THIS PROFESSIONAL SERVICES AGREEMENT (the "Agreement") is made at
Orange, California, on this 16th day of February 2023 (the "Effective Date")by and
between the. CITY OF ORANGE, a municipal corporation ("City"), and STANTEC
CONSULTING SERVICES INC.,a New York corporation ("Contractor"),who agree as follows:
1. Services. Subject to the terms and conditions set forth in this Agreement,
Contractor shall provide to the reasonable satisfaction of City the services set forth in Exhibit"A,"
which is attached hereto and incorporated herein by reference. As a material inducement to City
to enter into this Agreement,Contractor represents and warrants that it has thoroughly investigated
and considered the scope of services and fully understands the difficulties and restrictions in
performing the work. The services which are the subject of this Agreement are not in the usual
course of City's business and City relies on Contractor's representation that it is independently
engaged in the business of providing such services and is experienced in performing the work.
Contractor shall perform all services in a manner reasonably satisfactory to City and in a manner
in conformance with the standards of quality normally observed by an entity providing such
services to a municipal agency. All services provided shall conform to all federal, state and local
laws, rules and regulations and to the best professional standards and practices. The terms and
conditions set forth in this Agreement shall control over any terms and conditions in Exhibit "A"
to the contrary.
Tuan Cao, Senior Civil Engineer("City's Project Manager"), shall be the person to whom
Contractor will report for the performance of services hereunder. It is understood that Contractor's
performance hereunder shall be under the supervision of City's Project Manager (or his/her
designee), that Contractor shall coordinate its services hereunder with City's Project Manager to
the extent required by City's Project Manager, and that all performances required hereunder by
Contractor shall be performed to the satisfaction of City's Project Manager and the City Manager.
2. Compensation and Fees.
a. Contractor's total compensation for all services performed under this
Agreement, shall not exceed NINETEEN THOUSAND EIGHT HUNDRED SIXTY-EIGHT
DOLLARS and 00/100 ($19,868.00)without the prior written authorization of City.
b. The above compensation shall include all costs, including, but not limited
to, all clerical, administrative, overhead, insurance, reproduction, telephone, travel, auto rental,
subsistence and all related expenses.
3. Payment.
a. As scheduled services are completed, Contractor shall submit to City an
invoice for the services completed, authorized expenses and authorized extra work actually
performed or incurred.
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
b. All such invoices shall state the basis for the amount invoiced, including
services completed,the number of hours spent and any extra work performed.
c. City will pay Contractor the amount invoiced within thirty (30) days after
the approval of the invoice.
d. Payment shall constitute payment in full for all services, authorized costs
and authorized extra work covered by that invoice.
4. Change Orders. No payment for extra services caused by a change in the scope
or complexity of work, or for any other reason, shall be made unless and until such extra services
and a price therefor have been previously authorized in writing and approved by City as an
amendment to this Agreement. City's Project Manager is authorized to approve a reduction in the
services to be performed and compensation therefor,. All amendments shall set forth the changes
of work,extension of time,and/or adjustment of the compensation to be paid by City to Contractor
and shall be signed by the City's Project Manager, City Manager or City Council, as applicable.
5. Licenses. Contractor represents that it and any subcontractors it may engage,
possess any and all licenses which are required under state or federal law to perform the work
contemplated by this Agreement and that Contractor and its subcontractors shall maintain all
appropriate licenses, including a City of Orange business license, at its cost, during the
performance of this Agreement.
6. Independent Contractor. At all times during the term of this Agreement,
Contractor shall be an independent contractor and not an employee of City. City shall have the
right to control Contractor only insofar as the result of Contractor's services rendered pursuant to
this Agreement. City shall not have the right to control the means by which Contractor
accomplishes services rendered pursuant to this Agreement. Contractor shall, at its sole cost and
expense, furnish all facilities, materials and equipment which may be required for furnishing
services pursuant to this Agreement. Contractor shall be solely responsible for, and shall
indemnify, defend and save City harmless from all matters relating to the payment of its
subcontractors, agents and employees, including compliance with social security withholding and
all other wages, salaries, benefits, taxes, exactions, and regulations of any nature whatsoever.
Contractor acknowledges that it and any subcontractors, agents or employees employed by
Contractor shall not,under any circumstances,be considered employees of City,and that they shall
not be entitled to any of the benefits or rights afforded employees of City, including,but not limited
to, sick leave, vacation leave, holiday pay, Public Employees Retirement System benefits, or
health, life, dental, long-term disability or workers' compensation insurance benefits.
7. Contractor Not Agent. Except as City may specify in writing, Contractor shall
have no authority, express or implied, to act on behalf of City in any capacity whatsoever as an
agent. Contractor shall have no authority, express or implied, to bind City to any obligation
whatsoever.
2
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
8. Designated Persons. Only those qualified persons authorized by City's Project
Manager, or as designated in Exhibit"A," shall perform work provided for under this Agreement.
It is understood by the parties that clerical and other nonprofessional work may be performed by
persons other than those designated.
9. Assignment or Subcontracting. No assignment or subcontracting by Contractor
of any part of this Agreement or of funds to be received under this Agreement shall be of any force
or effect unless the assignment has the prior written approval of City. City may terminate this
Agreement rather than accept any proposed assignment or subcontracting. Such assignment or
subcontracting may be approved by the City Manager or his/her designee.
10. Time of Completion. Except as otherwise specified in Exhibit "A," Contractor
shall commence the work provided for in this Agreement within five(5)days of the Effective Date
of this Agreement and diligently prosecute completion of the work in accordance with the time
period set forth in Exhibit"A"hereto or as otherwise agreed to by and between the representatives
of the parties.
11. Time Is of the Essence. Time is of the essence in this Agreement. Contractor shall
do all things necessary and incidental to the prosecution of Contractor's work.
12. Reserved.
13. Delays and Extensions of Time. Contractor's sole remedy for delays outside its
control, other than those delays caused by City, shall be an extension of time. No matter what the
cause of the delay,Contractor must document any delay and request an extension of time in writing
at the time of the delay to the satisfaction of City. Any extensions granted shall be limited to the
length of the delay outside Contractor's control. If Contractor believes that delays caused by City
will cause it to incur additional costs, it must specify, in writing, why the delay has caused
additional costs to be incurred and the exact amount of such cost at the time the delay occurs. No
additional costs can be paid that exceed the not to exceed amount stated in Section 2.a, above,
absent a written amendment to this Agreement.
14. Products of Contractor. The documents, studies, evaluations, assessments,
reports, plans, citations, materials, manuals, technical data, logs, files, designs and other products
produced or provided by Contractor for this Agreement shall become the property of City upon
receipt. Contractor shall deliver all such products to City prior to payment for same. City may
use, reuse or otherwise utilize such products without restriction.
15. Equal Employment Opportunity. During the performance of this Agreement,
Contractor agrees as follows:
a. Contractor shall not discriminate against any employee or applicant for
employment because of race, color, religion, sex, national origin, mental or physical disability, or
any other basis prohibited by applicable law. Contractor shall ensure that applicants are employed,
and that employees are treated during employment, without regard to their race, color, religion,
sex, national origin, mental or physical disability, or any other basis prohibited by applicable law.
3
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
Such actions shall include,but not be limited to the following: employment,upgrading, demotion
or transfer,recruitment or recruitment advertising,layoff or termination,rates of pay or other forms
of compensation and selection for training, including apprenticeship. Contractor agrees to post in
conspicuous places, available to employees and applicants for employment, a notice setting forth
provisions of this non-discrimination clause.
b. Contractor shall, in all solicitations and advertisements for employees
placed by, or on behalf of Contractor, state that all qualified applicants will receive consideration
for employment without regard to race, color, religion, sex, national origin, mental or physical
disability, or any other basis prohibited by applicable law.
c. Contractor shall cause the foregoing paragraphs (a) and(b)to be inserted in
all subcontracts for any work covered by this Agreement, provided that the foregoing provisions
shall not apply to subcontracts for standard commercial supplies or raw materials.
16. Conflicts of Interest. Contractor agrees that it shall not make, participate in the
making, or in any way attempt to use its position as a consultant to influence any decision of City
in which Contractor knows or has reason to know that Contractor, its officers, partners, or
employees have a financial interest as defined in Section 87103 of the Government Code.
Contractor further agrees that it shall not be eligible to work as the design/build firm for the project
that is the subject of this Agreement.]
17. Indemnity.
a. To the fullest extent permitted by law, Contractor agrees to indemnify,
defend and hold City, its City Council and each member thereof, and the officers, officials, agents
and employees of City (collectively the "Indemnitees") entirely harmless from all liability arising
out of:
1) Any and all claims under workers' compensation acts and other
employee benefit acts with respect to Contractor's employees or Contractor's subcontractor's
employees arising out of Contractor's work under this Agreement, including any and all claims
under any law pertaining to Contractor or its employees' status as an independent contractor and
any and all claims under Labor Code section 1720 related to the payment of prevailing wages for
public works projects; and
2) Any claim, loss, injury to or death of persons or damage to property
caused by any act, neglect, default, or omission other than a professional act or omission of
Contractor, or person, firm or corporation employed by Contractor, either directly or by
independent contract, including all damages due to loss or theft sustained by any person, firm or
corporation including the Indemnitees, or any of them, arising out of, or in any way connected
with the work or services which are the subject of this Agreement, including injury or damage
either on or off City's property; but not for any loss, injury, death or damage caused by the active
negligence or willful misconduct of City. Contractor, at its own expense, cost and risk, shall
indemnify any and all claims, actions, suits or other proceedings that may be brought or instituted
against the Indemnitees on any such claim or liability covered by this subparagraph, and shall pay
4
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
or satisfy any judgment that may be rendered against the Indemnitees, or any of them, in any
action, suit or other proceedings as a result of coverage under this subparagraph.
b. To the fullest extent permitted by law, and as limited by California Civil
Code 2782.8, Contractor agrees to indemnify and hold Indemnitees harmless from all liability
arising out of any claim, loss, injury to or death of persons or damage to property to the extent
caused by its negligent professional act or omission in the performance of professional services
pursuant to this Agreement.
c. Except for the Indemnitees, the indemnifications provided in this
Agreement shall not be construed to extend any third party indemnification rights of any kind to
any person or entity which is not a signatory to this Agreement.
d. The indemnities set forth in this section shall survive any closing,
rescission, or termination of this Agreement, and shall continue to be binding and in full force and
effect in perpetuity with respect to Contractor and its successors.
18. Insurance.
a. Contractor shall carry workers' compensation insurance as required by law
for the protection of its employees during the progress of the work. Contractor understands that it
is an independent contractor and not entitled to any workers' compensation benefits under any
City program.
b. Contractor shall maintain during the life of this Agreement the following
minimum amount of comprehensive general liability insurance or commercial general liability
insurance: the greater of (1) One Million Dollars ($1,000,000) per occurrence; or (2) all the
insurance coverage and/or limits carried by or available to Contractor. Said insurance shall cover
bodily injury, death and property damage and be written on an occurrence basis.
c. Contractor shall maintain during the life of this Agreement, the following
minimum amount of automotive liability insurance: the greater of(1) a combined single limit of
One Million Dollars ($1,000,000); or (2) all the insurance coverage and/or limits carried by or
available to Contractor. Said insurance shall cover bodily injury, death and property damage for
all owned, non-owned and hired vehicles and be written on an occurrence basis.
d. Any insurance proceeds in excess of or broader than the minimum required
coverage and/or minimum required limits which are applicable to a given loss shall be available
to City. No representation is made that the minimum insurance requirements of this Agreement
are sufficient to cover the obligations of Contractor under this Agreement.
e. Each policy of general liability and automotive liability shall provide that
City, its officers, officials, agents, and employees are declared to be additional insureds under the
terms of the policy, but only with respect to the work performed by Contractor under this
Agreement. A policy endorsement to that effect shall be provided to City along with the certificate
of insurance. In lieu of an endorsement, City will accept a copy of the policy(ies)which evidences
5'
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
that City is an additional insured as a contracting party. The minimum coverage required by
Subsection 18.b and c, above, shall apply to City as an additional insured. Any umbrella liability
insurance that is provided as part of the general or automobile liability minimums set forth herein
shall be maintained for the duration of the Agreement.
f.Contractor shall maintain during the life of this Agreement professional
liability insurance covering errors and omissions arising out of the performance of this Agreement
with a minimum limit of One Million Dollars ($1,000,000) per claim. Contractor agrees to keep
such policy in force and effect for at least five (5) years from the date of completion of this
Agreement.
g. The insurance policies maintained by Contractor shall be primary insurance
and no insurance held or owned by City shall be called upon to cover any loss under the policy.
Contractor will determine its own needs in procurement of insurance to cover liabilities other than
as stated above.
h. Before Contractor performs any work or prepares or delivers any materials,
Contractor shall furnish certificates of insurance and endorsements, as required by City,
evidencing the aforementioned minimum insurance coverages on forms acceptable to City,which
shall provide that the insurance in force will not be canceled or allowed to lapse without at least
ten (10) days' prior written notice to City.
i.Except for professional liability insurance coverage that may be required by
this Agreement, all insurance maintained by Contractor shall be issued by companies admitted to
conduct the pertinent line of insurance business in California and having a rating of Grade A or
better and Class VII or better by the latest edition of Best Key Rating Guide. In the case of
professional liability insurance coverage, such coverage shall be issued by companies either
licensed or admitted to conduct business in California so long as such insurer possesses the
aforementioned Best rating.
j Contractor shall immediately notify City if any required insurance lapses or
is otherwise modified and cease performance of this Agreement unless otherwise directed by City.
In such a case, City may procure insurance or self-insure the risk and charge Contractor for such
costs and any and all damages resulting therefrom, by way of set-off from any sums owed
Contractor.
k. Contractor agrees that in the event of loss due to any of the perils for which
it has agreed to provide insurance, Contractor shall look solely to its insurance for recovery.
Contractor hereby grants to City,on behalf of any insurer providing insurance to either Contractor
or City with respect to the services of Contractor herein,a waiver of any right to subrogation which
any such insurer may acquire against City by virtue of the payment of any loss under such
insurance.
1.Contractor shall include all subcontractors, if any, as insureds under its
policies or shall furnish separate certificates and endorsements for each subcontractor to City for
6
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
review and approval. All coverages for subcontractors shall be subject to all of the requirements
stated herein.
19. Termination. City may for any reason terminate this Agreement by giving
Contractor not less than five (5) days' written notice of intent to terminate. Upon receipt of such
notice, Contractor shall immediately cease work, unless the notice from City provides otherwise.
Upon the termination of this Agreement, City shall pay Contractor for services satisfactorily
provided and all allowable reimbursements incurred to the date of termination in compliance with
this Agreement, unless termination by City shall be for cause, in which event City may withhold
any disputed compensation. City shall not be liable for any claim of lost profits.
20. Maintenance and Inspection of Records. In accordance with generally accepted
accounting principles, Contractor and its subcontractors shall maintain reasonably full and
complete books, documents, papers, accounting records, and other information (collectively, the
records")pertaining to the costs of and completion of services performed under this Agreement.
City and its authorized representatives shall have access to and the right to audit and reproduce
any of Contractor's records regarding the services provided under this Agreement. Contractor shall
maintain all such records for a period of at least three (3)years after termination or completion of
this Agreement. Contractor agrees to make available all such records for inspection or audit at its
offices during normal business hours and upon three(3)days' notice from City,and copies thereof
shall be furnished if requested.
21. Compliance with all Laws/Immigration Laws.
a. Contractor shall be knowledgeable of and comply with all local, state and
federal laws which may apply to the performance of this Agreement.
b. If the work provided for in this Agreement constitutes a"public works," as
that term is defined in Section 1720 of the California Labor Code,for which prevailing wages must
be paid, to the extent Contractor's employees will perform any work that falls within any of the
classifications for which the Department of Labor Relations of the State of California promulgates
prevailing wage determinations, Contractor hereby agrees that it, and any subcontractor under it,
shall pay not less than the specified prevailing rates of wages to all such workers. The general
prevailing wage determinations for crafts can be located on the website of the Department of
Industrial Relations (www.dir.ca.gov/DLSR). Additionally, to perform work under this Contract,
Contractor must meet all State registration requirements and criteria, including project compliance
monitoring.
c. Contractor represents and warrants that it:
1) Has complied and shall at all times during the term of this
Agreement comply, in all respects, with all immigration laws, regulations, statutes, rules, codes,
and orders, including, without limitation, the Immigration Reform and Control Act of 1986
IRCA); and
7
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
2) Has not and will not knowingly employ any individual to perform
services under this Agreement who is ineligible to work in the United States or under the terms of
this Agreement; and
3) Has properly maintained, and shall at all times during the term of
this Agreement properly maintain, all related employment documentation records including,
without limitation, the completion and maintenance of the Form I-9 for each of Contractor's
employees; and
4) Has responded, and shall at all times during the term of this
Agreement respond, in a timely fashion to any government inspection requests relating to
immigration law compliance and/or Form 1-9 compliance and/or worksite enforcement by the
Department of Homeland Security, the Department of Labor, or the Social Security
Administration.
d. Contractor shall require all subcontractors or subconsultants to make the
same representations and warranties as set forth in Subsection 21.c.
e. Contractor shall, upon request of City, provide a list of all employees
working under this Agreement and shall provide,to the reasonable satisfaction of City,verification
that all such employees are eligible to work in the United States. All costs associated with such
verification shall be borne by Contractor. Once such request has been made, Contractor may not
change employees working under this Agreement without written notice to City,-accompanied by
the verification required herein for such employees.
f.Contractor shall require all subcontractors or sub-consultants to make the
same verification as set forth in Subsection 21.e.
g. If Contractor or subcontractor knowingly employs an employee providing
work under this Agreement who is not authorized to work in the United States, and/or fails to
follow federal laws to determine the status of such employee,that shall constitute a material breach
of this Agreement and may be cause for immediate termination of this Agreement by City.
h. Contractor agrees to indemnify and hold City, its officers, officials, agents
and employees harmless for, of and from any loss, including but not limited to fines,penalties and
corrective measures City may sustain by reason of Contractor's failure to comply with said laws,
rules and regulations in connection with the performance of this Agreement.
22. Governing Law and Venue. This Agreement shall be construed in accordance
with and governed by the laws of the State of California and Contractor agrees to submit to the
jurisdiction of California courts. Venue for any dispute arising under this Agreement shall be in
Orange County, California.
23. Integration. This Agreement constitutes the entire agreement of the parties. No
other agreement,oral or written,pertaining to the work to be performed under this Agreement shall
be of any force or effect unless it is in writing and signed by both parties. Any work performed
8
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
which is inconsistent with or in violation of the provisions of this Agreement shall not be
compensated.
24. Notice. Except as otherwise provided herein, all notices required under this
Agreement shall be in writing and delivered personally, by e-mail, or by first class U.S. mail,
postage prepaid, to each party at the address listed below. Either party may change the notice
address by notifying the other party in writing. Notices shall be deemed received upon receipt of
same or within three (3) days of deposit in the U.S. Mail,whichever is earlier. Notices sent by e-
mail shall be deemed received on the date of the e-mail transmission.
CONTRACTOR" CITY"
Stantec Consulting Services Inc. City of Orange
38 Technology Drive 300 E. Chapman Avenue
Irvine, CA 92618 Orange, CA 92866-1591
Attn.: Jeff Dunn Attn.: Jose Diaz
Telephone: 949-521-3110 Telephone: 714-288-2475
E-Mail: jeff.dunn@stantec.com E-Mail: jdiaz@cityoforange.org
25. Counterparts. This Agreement may be executed in one or more counterparts,each
of which shall be deemed an original, but all of which together shall constitute one and the same
instrument. Signatures transmitted via facsimile and electronic mail shall have the same effect as
original signatures.
Remainder of page intentionally left blank; signatures on next page]
9
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
IN WITNESS of this Agreement, the parties have entered into this Agreement as of the
year and day first above written.
CONTRACTOR" CITY"
STANTEC CONSULTING SERVICES INC.,CITY OF ORANGE, a municipal corporation
a New York corporation
DocuSigned by: DocuSigned by:
By: 34 V By: t&emaS
Printea 1 1ame 17tff.Dunn rfi,63M6a9t3itElSela,Interim City Manager
Title:Principal
By: APPROVED AS TO FORM:
Printed Name: DocuSigned by:
Title: C k
07BC182A28A 1451..
Mary E. Binning, City Attorney
NOTE:City requires the following signature(s) on behalf of the Contractor:
1)the Chairman of the Board,the President or a Vice-President,AND (2)the
Secretary, the Chief Financial Officer, the Treasurer, an Assistant Secretary
or an Assistant Treasurer. If only one corporate officer exists or one corporate
officer holds more than one corporate office, please so indicate. OR
The corporate officer named in a corporate resolution as authorized to enter
into this Agreement. A copy of the corporate resolution, certified by the
Secretary close in time to the execution of the Agreement,must be provided to
City.
10
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
EXHIBIT "A"
SCOPE OF SERVICES
Beneath this sheet.]
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DB0DA32E31
Stantec Consulting Services Inc.
Stantec 38 Technology Drive Suite 200, Irvine CA 92618-5312
January 24,2023
File: 184083000
Attention: Tuan Cao,PE
City of Orange,Public Works Department-Water Division
189 S.Water St.
Orange,CA 92866
Reference: Proposal for a Water Model Analysis for the Proposed 840 The City Drive Project and
Miscellaneous Model Analyses Services
Dear Tuan,
We are pleased to provide you with this proposal to prepare a hydraulic model analysis for the proposed
840 The City Drive South Project and Miscellaneous Model Analyses Services. We understand that the 840
The City Drive Project is a mixed-use development that will include a new multi-story residential building
with 225 dwelling units. To support the development and increase in water demand, the Water Division has
proposed a number of water service and fire service improvement connections including upsizing the 8-inch
water main fronting the 840 The City Drive Project with a 12-inch water main in Garden Grove Boulevard
and The City Drive.
Stantec has been requested to perform a hydraulic model analysis of this area by adding the proposed
Project water demand and fire flow requirements to the current hydraulic model to verify the diameter
required at this location to serve the 840 The City Drive Project.
In addition to the proposes 840 The City Drive Project, we will perform other future miscellaneous hydraulic
model analyses as determine and requested by the Water Division.
The following is our proposed scope of services, schedule, and fee.
Scope
1. 840 The City Drive Project Model Analysis
1.1 Project Management, Meetings, and Coordination
We will conduct a project kick off meeting to discuss the project details, available data, scope, and
schedule for this project. In addition to this kick off meeting and project management/coordination
activities,we anticipate one additional meeting to review preliminary results and any technical
memorandum comments provided by the Water Division. These meetings are assumed to be
virtual.
Design with community in mind
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
January 24,2023
Tuan Cao,PE
Page 2 of 3
Reference: Proposal for a Water Model Analysis for the Proposed 840 The City Drive Project and Miscellaneous Model Analyses Services
1.2 Project Demands
We will prepare a water demand analysis for the proposed Project. Project details as far as acres,
building square footage, and number dwelling units will be based on the"The City Dr South 840
Project"information provided by the City with the request for proposal.
In addition to the average water usage, we will estimate the peak water demand usage for
maximum day and peak hourly demand using the peaking factors from the Water Master Plan
Update.
We assume that the developer will provide any known fire flow requirements specifically for this
Project as provided by the Orange County Fire Authority. If not, the fire code will be used to
estimate fire flow requirements based on the proposed building type(s)and square footages, as
provided to us.
1.3 Updates to the Hydraulic Model
We will use the calibrated hydraulic model prepared for the recent Water System.Master Plan
Update prepared by Stantec. This model will be updated as necessary with the appropriate nodes
and hydrant locations. Two scenarios will be added in the model to represent the proposed Project
demands, one for existing demand conditions and one for future demand conditions.
We will note system and supply operations in the pressure zone contained in the model, such as
wells assumed in operation and imported water connections and verify these operating conditions
with the City before completing the analysis.
1.4 Hydraulic Model Analysis
We will analyze the existing and proposed system scenarios and investigate the impacts the
Project water demands and fire flow requirements to the existing water system. The model analysis
will include a maximum day demands 24-hr EPS analysis which will include peak hour demand
conditions results and maximum day plus fire flow analyses. The results will be evaluated against
City planning and design criteria. For each scenario will show system pressures modeled at each
service connection to the Project and residual fire flow at each hydrant fronting the Project.
Velocities in the water mains will also be reported.The model will be tested for the existing 8-inch
water and proposed 12-inch water main.Any other deficiencies in the existing system will be
reported along with recommended improvements.
1.5 Prepare a Brief Technical Memorandum
We will prepare a technical memorandum describing the existing and proposed infrastructure with
brief description of the demands, assumptions, and analysis.We anticipate that figures will be
provided illustrating the Project location, and existing and proposed water mains.
A draft technical memorandum will be prepared for the City's review. Based on review comments
received, we will prepare a final technical memorandum.
Design with community in mind
DocuSign Envelope ID:F570B2A8-B4D5-402A-8681-B3DBODA32E31
January 24,2023
Tuan Cao,PE
Page 3 of 3
Reference: Proposal for a Water Model Analysis for the Proposed 840 The City Drive Project and Miscellaneous Model Analyses Services
Schedule
We anticipate that we will be able to begin work immediately upon receipt of a fully executed
agreement and notice to proceed from the City. We anticipate that the analysis and draft technical
memorandum will be completed within less than two weeks from the notice to proceed.
2. Miscellaneous Model Analyses
In addition to the 840 The City Drive Project,we will perform miscellaneous model analyses as
determined and requested by the Water Division. Each model analysis is assumed to be similar in
scope as Task 1 for the 840 The City Drive Project.We assume that up to three additional model
analyses will be performed.
Budget
To perform the scope of services as described herein,we respectfully propose a budget of$19,868, with
5,232 required for the 840 The City Drive Project and the remaining budget of$14,636 is reserved for the
future miscellaneous model analyses. The remaining budget of$14,636 will not be used until a request for
a model task is received and authorization is provided by the Water Division.The budget is in accordance
with the labor hours breakdown by task that is attached. This budget is assumed to be invoiced monthly on
a time and materials not-to-exceed basis.
If you have any questions or concerns with this proposal, please do not hesitate to contact me at the
information below.
Regards,
Stantec Consulting Services Inc.
eff Dunn PE
Ph:949 521 3110
jeff.dunn@stantec.com
Attachment: Labor Hours by Task
Design with community in mind
DocuSign Envelope ID:F570B2A8-B4D5-402A-86B1-B3DBODA32E31
Ci FEE ESTIMATE - 840 The City Drive and Miscellaneous Model Analyses
1/4
a
0
v. a
c.,
c 5.,
r,t
Q Zaa
Name Dunn,Jeff
Pirijanyan, Carrillo,
Adelina Roxana
Project Billing Rate 256 232 189
Total Hours 17 18 60
Fee(T&M) 4,352 $4,176 $11,340
V '
67° '-
Y 7.7447,' au
r'r> aye `= R 6-, .:Task Task Name Hours Hours
1 840 The City Drive Model Analysis 5 4 16 25 5,232
1.1 Project Management and Meetings 2 1 3 701
1.2 Project Demands 1 1 189
1.3 Updates to the Hydraulic Model 1 1 4 6 1,244
1.4 Hydraulic Model Analysis 1 4 5 988
1.5 Prepare a I-nefTechnical Memorandum 2 2 6 10 2,110
5 Miscellaneous Model Analyses 12 14 44 70 14,636
Total 95 19,868